Construction Delay definition

Construction Delay means delays in construction of the Leasehold Improvements attributable to (i) strikes, lockouts, labor troubles, inability to procure materials, power failure, restrictive governmental laws or regulations, civil disturbances, war, acts of terrorism, failure to secure permits within the normal time frames, lightening, earthquake, fire, storm, hurricane, tornado, flood, explosion and any other similar cause beyond the reasonable control of Lessee, or (ii) material interference by Lessor; provided, however, as a condition to claiming the benefit of any extension of the Outside Request Date due to such Construction Delay, Lessee shall provide Lessor with written notice of such Construction Delay, within thirty (30) days of Lessee’s knowledge thereof and the nature of its impact upon Lessee’s completion of the Leasehold Improvements and Lessee shall thereafter keep Lessor regularly informed of the status of such Construction Delay and its impact upon the completion of the Leasehold Improvements.
Sample 1Sample 2Sample 3
Construction Delay means any delay caused by an act or omission of either party, any tenant, or their respective employees, agents, contractors or subcontractors in connection with the design and construction of the Mall Improvements that is deemed a Construction Delay under this Agreement.
Sample 1Sample 2
Construction Delay has the meaning set forth in Paragraph 25.3.2 below. SCHEDULE 6 TO EXHIBIT B
Sample 1Sample 2

Examples of Construction Delay in a sentence

  • Investigating Causes of Construction Delay in Ethiopian Construction Industries.

  • Major Construction Delay Factors in Portugal, the UK, and the US.

  • Construction Delay Analysis Techniques—A Review of Application Issues and Improvement Needs.

  • Now days, the global business is transformed because of high pace innovation and development in the field of information technology (IT).

  • The marriage would end in divorce in 1930, and in estrangement from her child, who lived with Bullitt.

  • If Seller achieves Commercial Operation for the Facility to occur by the Guaranteed Commercial Operation Date, all Construction Delay Damages paid by Seller shall be refunded to Seller.

  • We discuss this risk in section 6.4 of this report.▪ Construction Delay Risk, which refers to the impact of unforeseen construction delays to the expected NPV of a project.

  • An Investigation into the Use of Construction Delay and Disruption Analysis Methodologies (Doctoral dissertation).

  • Construction Delay Risk Many respondents noted that the CfD regime increases risk in the event of construction delays relative to the RO, due to all projects being potentially subject to penalties for late delivery, or even loss of support.

  • Patil (2014) “Identification of Critical Construction Delay Factors” International Journal of Latest Trends in Engineering and Technology, Vol.


More Definitions of Construction Delay

Construction Delay means any of the following:
Sample 1Sample 2
Construction Delay means a material delay in the construction of the New Improvements for the Project that affects the Construction Timetable and is the result of (i) force majeure as described in Section 14.6, or (ii) the inability of the Company, through no fault of its own, to obtain the necessary permits and approvals of the City of Austin, or other governmental entity, in a timely manner.
Sample 1
Construction Delay means the Construction Work is the discontinued due to acts or matters within Property Owner’s control for a period of fifteen (15) or more consecutive days.
Sample 1
Construction Delay means delays incurred by reason of Tenant's failure to deliver the Operation Plan by August 1, 1999, Tenant's failure to approve the Plans and Specifications as set forth in Section 17(a) or changes requested by Tenant in the Plans and Specifications after Tenant's approval thereof, and for such additional time as is equal to the time lost by Landlord or Landlord's contractors or suppliers in connection with the performance of Landlord's work and/or the construction of the Demised Premises and related improvements due to industry-wide strikes or other labor troubles that are not specific to Landlord or the Demised Premises, governmental restrictions and limitations not known to Landlord (or reasonably capable of being known to Landlord) as of the Lease Date, war or other national emergency, non-availability of materials or supplies, delay in transportation, accidents, floods, fire, damage or other casualties, weather or other conditions, acts or omissions of Tenant, or delays by utility companies in bringing utility lines to the Demised Premises to the extent not resulting from Landlord's failure to order or apply for the same in a timely manner. For purposes of this Lease, the term "substantial completion" or any grammatical variation thereof shall mean sufficient completion of construction of the Demised Premises in accordance with the Plans and Specifications (including the Performance Specifications) so that Tenant can lawfully occupy the Demised Premises for the uses permitted herein, subject only to minor punchlist items, the completion of which will not interfere with such permitted uses by Tenant, as evidenced by the delivery by Landlord to Tenant of (i) a Certificate of Occupancy or its equivalent (or Temporary Certificate of Occupancy or its equivalent) for the Demised Premises issued by the appropriate governmental authority if so required by applicable law, and (ii) a Certificate of Substantial Completion on standard AIA Form G-704 certified by Landlord's architect, working in good faith together with such duly licensed Tennessee architect, if any, as may be selected by Tenant as Tenant's architect by written notice to Landlord given, if at all, within thirty (30) days of the Lease Date.
Sample 1
Construction Delay shall have the meaning set forth on Schedule 1-1 attached hereto. Contiguous Remainder Space – “Contiguous Remainder Space” shall have the meaning set forth on Schedule 1-4 attached hereto. Delivery Date – “Delivery Date” shall mean the date that Landlord’s Work is substantially completed. Delay Inception Date – “Delay Inception Date” shall mean, in each applicable instance in this Lease where such term is expressly provided, the date on which an actual delay in Tenant’s performance of Tenant’s Initial Improvements or Tenant’s occupancy of the Demised Premises for the ordinary conduct of Tenant’s business occurs solely as a result of the situation (i.e., failure by Landlord to perform or a Construction Delay) set forth in the applicable instance; provided, however, that no such delay shall be deemed to have occurred prior to the date that is the earlier to occur of the date on which (x) Tenant delivers a notice to Landlord stating that Tenant’s performance of Tenant’s Initial Improvements or Tenant’s occupancy of the Demised Premises for the ordinary conduct of Tenant’s business is actually so delayed, which notice may be sent via e-mail to XXxxxxxx@xxxxxxxxxxx.xxx and XXxXxxxx@xxxxxxxxxxx.xxx, or any other e-mail address provided by Landlord to Tenant from time to time (the “Delay Inception Notice”), and (y) Landlord obtains actual knowledge of the delay; provided that with respect to clause (y) above, in no event shall such date be more than five (5) Business Days prior to Landlord’s receipt of the Delay Inception Notice. Demised Premises – “Demised Premises” shall mean, collectively, the entire rentable area of the FTI Units, as shown on the shaded portion of the plan annexed hereto as Exhibit “A” and made a part hereof. Designated Broker – “Designated Broker” shall collectively mean Colliers International NY LLC and JLL, Inc. Disabilities Act – “Disabilities Act” shall mean, collectively, The Americans with Disabilities Act of 1990, Public Law 101-336, 42 U.S.C. § 12101 et seq. and Local Law 58 of 1988, each as modified and supplemented from time to time, together with all regulations promulgated in connection therewith. Existing Lender – “Existing Lender” shall mean Xxxxx Fargo Bank, National Association. Expansion Notice Date – “Expansion Notice Date” shall have the meaning set forth on Schedule 1-5 attached hereto. Expiration Date – “Expiration Date” shall mean the date set forth in Subsection 2.01B below, as same may be extended pursuant to the ter...
Sample 1

Related to Construction Delay

  • Construction Work means any work in connection with⎯

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Construction activity means any clearing, grading or excavation associated with large construction activity or associated with small construction activity.

  • Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).

  • Construction Budget means the fully-budgeted costs for the acquisition and construction of a given parcel of real property (including, without limitation, the cost of acquiring such parcel of real property, reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs) as reasonably determined by the Parent in good faith.

  • Construction defect means a deficiency in or a deficiency arising out of the design, specifications, surveying, planning, supervision, or observation of construction or construction of residential improvements that results from any of the following:

  • construction site means a workplace where construction work is being performed;

  • Construction waste means solid waste which is produced or generated during construction, remodeling, or repair of pavements, houses, commercial buildings, and other structures. Construction wastes include, but are not limited to lumber, wire, sheetrock, broken brick, shingles, glass, pipes, concrete, paving materials, and metal and plastics if the metal or plastics are a part of the materials of construction or empty containers for such materials. Paints, coatings, solvents, asbestos, any liquid, compressed gases or semi-liquids and garbage are not construction wastes.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Construction Debt means debt incurred to fund (a) all or a portion of a Capital Improvement, (b) interest payments (including periodic net payments under related interest rate swap agreements) and related fees on other Construction Debt or (c) distributions (including incremental Incentive Distributions) on Construction Equity.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Construction Phase means that Phase of the Project which shall commence after the Authority provides the Trade Contractor with written Notice to Proceed with the Construction Phase.

  • Construction Costs means land costs, all costs paid to construct and complete the Improvements, as specified on Exhibit "B" attached hereto and made a part hereof.

  • Construction Cost means and includes the cost of the entire construction of the Project, including all supervision, materials, supplies, labor, tools, equipment, transportation and/or other facilities furnished, used or consumed, without deduction on account of penalties, liquidated damages or other amounts withheld from payment to the contractor or contractors, but such cost shall not include the Consulting Engineer/Architect's fee, or other payments to the Consulting Engineer/Architect and shall not include cost of land or Rights-of-Way and Easement acquisition.

  • Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.

  • Direct Construction Cost means the sum of the amounts that the Construction Manager actually and necessarily incurs for General Conditions Costs, Cost of the Work and Construction Manager’s Contingency during the Construction Phase as allowed by this Agreement. Direct Construction Cost does not include Pre-Construction Phase Fees or Construction Phase Fees.

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;

  • Constructional Plant means all appliances or things whatever nature required in or about the execution, completion or maintenance of the works or temporary works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work or temporary housing, hutting, office, stores, etc.,

  • Tenant Delays means delays caused by: (i) requirements of the Plans and Specifications requested by Tenant that do not conform to Landlord’s building standards for office and lab build-out, or which contain long lead-time or non-standard items requested by Tenant; provided that Landlord has notified Tenant of such deviations upon execution of this Lease (ii) any material change in the Plans and Specifications requested by Tenant and agreed to by Landlord; (iii) any request by Tenant for a delay in the commencement or completion of the Initial Tenant Improvements for any reason; (iv) Tenant delay in finalizing and approving the design of the vivarium and value engineering of same or (v) any other act or omission of Tenant or its employees, agents or contractors which reasonably inhibits the Landlord from timely completing the Initial Tenant Improvements including, without limitation any delays caused by Tenant’s presence in the Premises prior to the Term Commencement Date. The Premises shall not be deemed to be incomplete if only minor or insubstantial details of construction, decoration or mechanical adjustments remain to be done which do not unreasonably interfere with Tenant’s occupancy of the Premises. If as a result of Tenant Delays the Premises are deemed ready for Tenant’s occupancy, pursuant to the foregoing (and the term shall have commenced by reason thereof), but the Premises are not in fact actually ready for Tenant’s occupancy, Tenant shall not (except with Landlord’s consent not to be unreasonably withheld, conditioned or delayed) be entitled to take possession of the Premises for the permitted use until the Premises are in fact actually ready for such occupancy.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Construction and demolition debris means and includes:

  • Project Completion Date means the date on which the Completion Certificate is issued;