Completion of Landlord Work definition

Completion of Landlord Work means the completion of any applicable Landlord Work, as evidenced by (i) a certification from both the Sellers and the applicable third-party contractor (under all applicable Work Agreements) that all such Landlord Work has been completed and fully paid for in accordance with (x) the applicable Lease or License, pursuant to which such Landlord Work is required to be undertaken (provided that no third-party contractor shall be required make any certification as to the subject matter of this clause (x)), (y) the applicable Work Agreements and (z) the plans and specifications, and other drawings in respect of such Landlord Work, (ii) final lien waivers from all applicable contractors and (iii) confirmation from the applicable Tenant or Licensee that such Landlord Work has been completed in accordance with the Lease or License, as applicable (provided that such confirmation shall not be required in order to evidence completion of Landlord Work if and to the extent (x) Sellers provide evidence to Purchaser that Sellers have requested such confirmation, (y) the applicable Tenant or Licensee has not provided such confirmation and (z) Sellers represents to Purchaser that the applicable Tenant or Licensee has not either (1) refused to provide such confirmation or (2) stated to Sellers (or the applicable third-party contractor under the applicable Work Agreements) that such Landlord Work has not been completed in accordance with the Lease or License, as applicable.
Sample 1Sample 2Sample 3

Examples of Completion of Landlord Work in a sentence

  • Sellers shall at all times use their commercially reasonable efforts to cause Completion of Landlord Work to occur prior to the Closing, in respect of all Landlord Work.

  • Notwithstanding anything contained herein to the contrary, Tenant shall have three hundred (300) days from the Substantial Completion of Landlord Work and the Base Building Work in which to discover and notify Landlord of any latent defects in the Landlord Work and/or the Base Building Work.

  • To the extent that awaiting any such overdue payment from Tenant delays the Substantial Completion of Landlord Work, such delay shall be a Tenant Delay and the Landlord Work shall be deemed Substantially Complete on the date such Landlord Work would have been completed but for awaiting such payment.

  • Pay and discharge as the same shall become due and payable, all Taxes upon it or its properties or assets that, if not paid, would reasonably be expected to result in a Material Adverse Effect, unless such Taxes are being contested in good faith by appropriate proceedings diligently conducted.

  • DELIVERY DATE: The date of Substantial Completion of Landlord Work, which Landlord estimates will occur on or before May 31, 2019 (the “Anticipated Delivery Date”).

  • To the extent that the request by Tenant for any change or the performance of work pursuant to any change delays the Substantial Completion of Landlord Work, such delay shall be a Tenant Delay and the Landlord Work shall be deemed Substantially Complete on the date such Landlord Work would have been completed but for such delay.

  • A Certificate of Completion of Landlord Work shall be defined as written certification by the Architect and General Contractor that all of the Landlord Work as specified in Exhibit C has been completed, paid for and all liens have been released.

  • Except for Defects stated in such notice and Latent Defects (defined below) of which Tenant gives Landlord notice within ninety (90) days after Substantial Completion of Landlord Work, Tenant shall be conclusively deemed to have accepted the Premises “AS IS” in the condition existing on the date Tenant first takes possession, and to have waived all claims relating to the condition of the Premises.

Related to Completion of Landlord Work

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Tenant Improvements Defined in Exhibit B, if any.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Construction Work means any work in connection with⎯

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Work Letter means the work letter between Landlord and Tenant regarding the construction of the Tenant Improvements, if any, in the form of Exhibit C.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.

  • Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Premises Building Partial Damage shall herein mean damage or destruction to the building of which the Premises are a part to the extent that the cost of repair is less than 50% of the then replacement cost of such building as a whole.

  • Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.

  • Building Project means the aggregate combined parcel of land on a portion of which are the improvements of which the Premises form a part, with all the improvements thereon, said improvements being a part of the block and lot for tax purposes which are applicable to the aforesaid land.

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Substantial alteration means an alteration that has a major impact on the architectural features, characteristics, appearance, or integrity of a structure or lot. The term does not include routine maintenance that is reasonably necessary to maintain a dealership facility in attractive condition and does not include any changes to items protected by federal intellectual property rights.

  • Installation Work means the construction and installation of the System and the Start-up, testing and acceptance (but not the operation and maintenance) thereof; all performed by or for the Power Producer at the Premises.

  • Subleased Premises means such portions of the Leased Premises being particularly identified on Schedule B, which the parties agree, for the purposes of this Sublease and any square footage calculations pursuant hereto, is approximately 42,244 square feet of office (21,068 square feet on the third floor and 21,176 square feet on the seventh floor) and approximately 9.4312% of common space (building rentable area is 447,917 square feet).

  • Construction Completion means physical construction of a cleanup action component is complete.

  • On-premises sign means a sign advertising activities conducted or maintained on the property on which it is located. The boundary of the property shall be as determined by tax rolls, deed registrations, and apparent land use delineations. If a sign consists principally of brand name or trade name advertising and the product or service advertised is only incidental to the principal activity conducted or maintained on the property, or if the sign brings rental income to the property owner or sign owner, it shall be considered the business of outdoor advertising and not an on-premises sign. On-premises sign does not include a sign on a narrow strip of land contiguous to the advertised activity, or a sign on an easement on adjacent property, when the purpose is clearly to circumvent the intent of this act.

  • demolition work means a method to dismantle, wreck, break, pull down or knock down of a structure or part thereof by way of manual labour, machinery, or the use of explosives;

  • Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.