Case of Force Majeure definition

Case of Force Majeure events defined in article 17 "Force Majeure" of this Contract.
Sample 1Sample 2Sample 3
Case of Force Majeure means an event beyond the reasonable control of the Seller, including, but not limited to, strikes, lockouts or other industrial disputes (involving the workforce of the Seller or any other party), failures on public utility or transport networks, fortuitous events, natural disasters, epidemics and pandemics, wars, revolts, terrorist attacks, civil commotion, intentional damage, compliance with any law, governmental directive, decree, rule or regulation, accidents, plant or machinery failures, fires, floods, storms, as well as the default by suppliers or subcontractors.
Sample 1Sample 2Sample 3
Case of Force Majeure events, facts or circumstances impacting on performance of the Contract and defined in Article 21.
Sample 1

Examples of Case of Force Majeure in a sentence

  • Section 118: Duty to Notify in Case of Force Majeure If a party is unable to perform a contract due to force majeure, it shall timely notify the other party so as to mitigate the loss that may be caused to the other party, and shall provide proof of force majeure within a reasonable time.

  • The suspension of one Party’s obligations as the result of a Case of Force Majeure has no effect on the term of the Contract.

  • The notification of a Case of Force Majeure in accordance with the preceding paragraph results in the suspension of performance of the obligation that has become impossible for the duration of the Force Majeure, subject to the provisions of Article 25.

  • In the event of a notified Case of Force Majeure, neither Party shall owe any indemnity or penalty to the other Party, and the contractual deadlines shall be extended by a period at least equivalent to that of the Case of Force Majeure.

  • If a Case of Force Majeure prevents Exail from fulfilling its contractual obligations for more than thirty (30) calendar days from the date of the aforementioned notification, and if no agreement has been reached on how to continue the performance of the Contract, the Contract may be terminated under the terms of Article 25.2.2. Exail will be paid for the Work performed and/or delivered to the Customer up to the date of termination.

  • On the assumption that a Case of Force Majeure were to prevent one of the Parties from performing all or part of its obligations under the Contract for a period in excess of thirty (30) days, the Parties will meet one another in order to examine the adaptations to be made to their respective obligations under the Contract to take account of this new situation.

  • Force Majeure: The Parties may terminate the Contract in the event of non-performance by the other Party of its obligations following the occurrence of a Case of Force Majeure, the duration of which exceeds thirty (30) calendar days from its notification to the other Party in accordance with Article 20.

  • A Case of Force Majeure includes any act, event, failure to perform, omission, or accident beyond CLAUDIE PIERLOT 's control and includes but is not limited to: 1.

  • As from the date of cessation of the Case of Force Majeure, the Shipper remains bound by its balancing obligation covered in Section 3.

  • For a straightforward Loading (excluding a Test Loading, Cooling Down or any other Service), and in the absence of any incident, failure or Case of Force Majeure, the Terminal's Operator undertakes to complete the Operation within a period of one (1) Slot.


More Definitions of Case of Force Majeure

Case of Force Majeure. (Force Majeure Event): the case (event) that takes place after the Date of Conclusion and: (a) is beyond the - reasonably understood – sphere of control of a Party, (b) it could not be reasonably expected that it would have been taken into account by the affected Party at the time of the conclusion of the Contract, (c) it could not have been reasonably prevented or addressed by the affected Party, even if the subject Party had fulfilled its obligations in the context of this Contract, and (d) it renders the fulfillment of all or of a significant part of the obligations of the affected Party, in the context of this Contract, impossible or unfeasible to such an extent -or unjustifiably or extremely expensive - that fulfillment thereof be reasonably considered impossible under the specific circumstances. Examples of Cases of Force Majeure are described here below:
Sample 1
Case of Force Majeure has the meaning established in Clause 13.06 (Force Majeure) of this Agreement. Assignor has the meaning established in Clause 9.0 (Intellectual Property Rights) of this Agreement.
Sample 1

Related to Case of Force Majeure

  • Event of Force Majeure means one of the following events:

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Use of force means: (A) Use of a dangerous instrument; or (B) use of actual physical force or violence or superior physical strength against the victim.

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Force Majeure Exception means any failure or delay in the performance of the Issuer's reporting obligation pursuant to Section 2.4 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Issuer shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Tenant Delays means delays caused by: (i) requirements of the Plans and Specifications requested by Tenant that do not conform to Landlord’s building standards for office and lab build-out, or which contain long lead-time or non-standard items requested by Tenant; provided that Landlord has notified Tenant of such deviations upon execution of this Lease (ii) any material change in the Plans and Specifications requested by Tenant and agreed to by Landlord; (iii) any request by Tenant for a delay in the commencement or completion of the Initial Tenant Improvements for any reason; (iv) Tenant delay in finalizing and approving the design of the vivarium and value engineering of same or (v) any other act or omission of Tenant or its employees, agents or contractors which reasonably inhibits the Landlord from timely completing the Initial Tenant Improvements including, without limitation any delays caused by Tenant’s presence in the Premises prior to the Term Commencement Date. The Premises shall not be deemed to be incomplete if only minor or insubstantial details of construction, decoration or mechanical adjustments remain to be done which do not unreasonably interfere with Tenant’s occupancy of the Premises. If as a result of Tenant Delays the Premises are deemed ready for Tenant’s occupancy, pursuant to the foregoing (and the term shall have commenced by reason thereof), but the Premises are not in fact actually ready for Tenant’s occupancy, Tenant shall not (except with Landlord’s consent not to be unreasonably withheld, conditioned or delayed) be entitled to take possession of the Premises for the permitted use until the Premises are in fact actually ready for such occupancy.

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Service Interruption means the cessation of electricity supply to an ICP for a period of 1 minute or longer, other than by reason of De-energisation of that ICP:

  • Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).

  • Certificate of Formation means the Certificate of Formation of the Company filed with the Secretary of State of the State of Delaware as referenced in Section 2.1, as such Certificate of Formation may be amended, supplemented or restated from time to time.

  • Unplanned Service Interruption means any Service Interruption where events or circumstances prevent the timely communication of prior warning or notice to the Trader or any affected Customer;

  • Service Commencement Date in respect of a Service or a particular instance of a Service means the date on which that particular Service or particular instance of a Service is first provided to the Customer, or as otherwise explicitly set out in this Agreement;

  • Planned Service Interruption means a Service Interruption that has been scheduled to occur in accordance with schedule 5;