Appointed Date definition

Appointed Date means the date of signing of this Agreement.

Appointed Date means the date of this Agreement.

Appointed Date means the date declared by the Authority as the project commencement date with the consent of the contractor, as per the process prescribed in Article 3 and 8 of this Agreement;

Examples of Appointed Date in a sentence

• The Contractor shall bear full risk in, and take full responsibility for, the care of the Works, and of the Materials, goods and equipment for incorporation therein, from the Appointed Date until the date of Completion Certificate, save and except to the extent that any such loss or damage shall have arisen from any wilful default or gross neglect of the Authority.

• The Parties agree that these works may be taken up and completed to the extent feasible by the Contractor, before declaration of the Appointed Date, but no claim against the Authority for delay shall survive during this period and that the undertaking of these works by the Contractor shall not count towards the Scheduled Construction Period of the project which starts counting only from the Appointed Date.

• The video recording shall be provided to the Authority no later than 15 (fifteen) days after the close of each quarter after the Appointed Date.

• The [730th (Seven Hundred and Thirty) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.

• The Scheme set out herein in its present form with or without any modification(s), approved or imposed or directed by the Hon’ble Tribunal or any other competent authority, or made as per the Scheme, shall be effective from the Appointed Date but shall be operative from the Effective Date.

More Definitions of Appointed Date

Appointed Date means the date on which all the Conditions Precedent are achieved and every Condition Precedent is either satisfied or waived, as the case may be, in accordance with the provisions of this Agreement, and such date shall be the date of commencement of the Contract Period;

Appointed Date means the date appointed under sub-section (3) of section 1;

Appointed Date means the date on which this Act comes into force;

Appointed Date or “Effective Date” means the date on which every Condition Precedent shall have been satisfied or waived prior to the Appointed Date and in the event all Conditions Precedent are not satisfied or waived, as the case may be, the Appointed Date shall be deemed to occur only when each and every Condition Precedent is either satisfied or waived, as the case may be.

Appointed Date means the date appointed for the commencement of this Act;

Appointed Date means the date appointed by the Minister under section one;

Appointed Date means the Effective Date;