Anticipated Project Completion Date definition

Anticipated Project Completion Date. The date six (6) months after the Anticipated Physical Completion Date.
Sample 1Sample 2
Anticipated Project Completion Date means the later of
Sample 1
Anticipated Project Completion Date means, subject to the occurrence of force majeure or other events beyond the reasonable control of the Authority, the estimated date of completion of the construction of the Project, which shall be December 31, 2020.
Sample 1

Examples of Anticipated Project Completion Date in a sentence

  • The information shall include: Consultancy Agreement No. Project Title Name of Lead Consultant Selected Names of Sub-Consultants Selected Consultancy Fee and Fee Basis Anticipated Project Commencement Date Anticipated Project Completion Date The above information shall remain on the website for 6 months after the agreement is executed.

  • Permit Expiration: An approved Permit shall be valid for a minimum of 1 year from date of approval by Department or Anticipated Project Completion Date, whichever is longer, but no more than 5 years.

  • An approved Permit shall be valid for 1 year from the date of approval by the Department or the Anticipated Project Completion Date, whichever is longer, but no more than 5 years.

  • Approximate Total Funding: $100,000, pending availability of funds Approximate Number of Awards: One Anticipated Award Date: April 15, 2018 Anticipated Project Completion Date: September 01, 2018 Additional Information: Applicants' budget submissions should be realistic and reflect anticipated actual costs required to implement the program(s) and the varying costs specific to programming needs.

  • Yandex, where the defendant was not itself foreign, but instead was the U.S.- based advertising subsidiary of the Russian search engine, Yandex.ru.

  • The coverage for "business income", including "rental income", will begin after the "Anticipated Project Completion Date" exceeds the Deductible Period shown in the Supplemental Declarations.

  • It will apply for a period of up to three consecutive weeks from the "Anticipated Project Completion Date" after the Deductible Period.

  • The coverage for "soft costs" will begin after the "Anticipated Project Completion Date" exceeds the Deductible Period shown in the Supplemental Declarations.

  • Program Description above.• Approximate Total Funding: $1,350,000.00, pending availability of funds• Approximate Number of Awards: One• Anticipated Award Date: July 01, 2019• Anticipated Project Completion Date: April 30, 2020• Additional Information: Applicants' budget submissions should be realistic and reflect anticipated actual costs required to implement the program(s) and the varying costs specific to programming needs.

  • Access: 16.01.2022.2. Apvienoto Naciju Organizacijas samita nosleguma dokumenta projekts attistibas programmas pienemsanai laikposmam pec 2015.gada (Draft Outcome Document of the United Nations Summit for the Adoption of the Post-2015 Development Agenda: Draft Resolution).


More Definitions of Anticipated Project Completion Date

Anticipated Project Completion Date. October 31, 2011.
Sample 1

Related to Anticipated Project Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Final Completion Date means the date on which Final Completion occurs.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Phase 1 means the first implementation phase of this section, beginning June 1, 2018 and ending May 31, 2022.

  • Project Year means the 12 month period beginning from the Effective Date and ending 12 months thereafter and each successive 12 month period following thereafter;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Project Implementation Unit or “PIU” means the unit referred to in Section I.A.1 of Schedule 2 to this Agreement.

  • Project area budget means a multiyear projection of annual or cumulative

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Work means the work required to complete the Project.

  • Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Project Improvements means site improvements and facilities that are: