Work Duration Schedules Sample Clauses

Work Duration Schedules. With each quote, the Contractor agrees to furnish a work duration schedule showing the order in which the Contractor proposes to perform the work, the durations in which the Contractor is to perform the work, and the relative dates on which the Contractor contemplates starting and completing project tasks, including the acquisition of materials, fabrication, and equipment. The County may determine the level of detail and the number of tasks required to be included on the schedule. Unless otherwise specified, the schedule shall be in the form of a Xxxxx chart work duration schedule of suitable scale to indicate appropriately the percentage of work scheduled for completion. At the discretion of the County, the Contractor may be required to furnish a Critical Path Method (CPM) schedule. The purpose of the Work Duration Schedule is to ensure adequate planning, coordination, and execution of the work, and to evaluate the progress of the work. The schedule indicates the dates for starting and completing various aspects of the work including, but not limited to, on-site construction activities as well as the submittal, approval, procurement, fabrication, and delivery of major items, materials and equipment. The schedule indicates phasing of work activities as required. The schedule provides the Contractor’s initial plan for the work based on its understanding of the Detailed Scope of Work, with the critical path highlighted.
Sample 1
AutoNDA by SimpleDocs

Related to Work Duration Schedules

  • Vacation Schedules (a) Employees shall submit their vacation requests to the supervisor on or before:

  • Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.

  • Work Schedules Workweeks and work shifts of different numbers of hours may be established by the Employer in order to meet business and customer service needs, as long as the work schedules meet federal and state laws.

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

  • Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement.

  • Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.

  • Alternative Work Schedules Alternative work schedule means an approved schedule for an Employee that deviates from the work week described in Section 1, Section 2, or a schedule that deviates from a worksite’s normal schedule. Employees who work a “shift work schedule” as part of a rotating group of individuals who must continuously maintain a 24-hour operation or facility are not eligible for an alternative work schedule.

  • Shift Schedules 1501 Shift schedules for a minimum of a four (4) week period shall be posted at least two (2) weeks in advance of the beginning of the scheduled period. Shifts within the minimum four (4) week period shall not be altered after posting except by mutual agreement between the nurse(s) concerned and the Employer. Requests for specific days off duty shall be submitted in writing at least two (2) weeks prior to posting and granted, if possible in the judgment of the Employer. 1502 Requests for interchanges in posted shifts or a portion thereof shall also be submitted in writing, co-signed by the nurse willing to exchange shifts with the applicant. Where reasonably possible, interchanges in posted shifts are to be completed within the posted shift schedule. It is understood that any change in shifts or days off initiated by the nurses and approved by the Employer shall not result in overtime costs to the Employer. 1503 Night shift shall be considered as the first shift of each calendar day. 1504 Master rotations for each nursing unit shall be planned by the Employer in meaningful consultation with the nurse(s) concerned. The process for meaningful consultation shall include:  Employer proposes a master rotation including the Employer established criteria and provides to Nurses concerned  Nurses are provided reasonable time to submit feedback and/or an alternate master rotation for consideration.  The amended or new master rotation is provided to Nurses for review. Nurses are provided with a reasonable time to submit feedback.  At each step of the consultation process the Union will be provided with the new or revised master rotation to ensure contract compliance.  Employer has the sole discretion to select the new master rotation and provides rationale for the selection. Master Rotations shall, unless otherwise mutually agreed between the nurse(s) concerned and the Employer, observe the conditions listed hereinafter:

Time is Money Join Law Insider Premium to draft better contracts faster.