Common use of Withholding for unpaid wages and liquidated damages Clause in Contracts

Withholding for unpaid wages and liquidated damages. The contracting officer will withhold from the contractor, from any monies payable on account of work performed by the contractor or subcontractor, such sums as may administratively be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the provisions of paragraph “b.”

Withholding for unpaid wages and liquidated damages. The contracting officer will Contracting Officer may withhold from the contractorContractor, from any monies moneys payable on account of work performed by the contractor Contractor or subcontractor, such sums amounts as may administratively be determined to be necessary to satisfy any liabilities of such contractor the Contractor or subcontractor for unpaid wages and liquidated damages as provided in the provisions of paragraph “b.”39.2 above.

Withholding for unpaid wages and liquidated damages. The contracting officer will Contracting Officer may withhold from the contractor, from any monies payable on account of work performed by the contractor or subcontractorContractor, such sums as may administratively be determined he or she determines to be necessary to satisfy any liabilities of such contractor Contractor or subcontractor for unpaid wages and liquidated damages as provided in the provisions of paragraph “b.”(b).‌

Withholding for unpaid wages and liquidated damages. The contracting officer will Contract Officer may withhold from the government prime contractor, from any monies payable on account of work performed by the contractor or subcontractor, such sums as may administratively be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the provisions of paragraph “b.”(b).