Termination of the Lease If for any reason the term of the Master Lease shall terminate prior to the Sublease Expiration Date, this Sublease shall automatically be terminated and Sublandlord shall not be liable to Subtenant by reason thereof unless said termination shall have been caused by the default of Sublandlord under the Master Lease, and said Sublandlord default was not as a result of a Subtenant default hereunder.
Termination of Master Lease If the Master Lease terminates for any reason prior to the expiration or other termination of this Sublease, this Sublease shall terminate concurrently therewith without any liability of Sublandlord to Subtenant and, except for any Subtenant obligations hereunder arising on or prior to the termination of this Sublease, following Subtenant’s surrender in compliance with Section 4.2 hereof, Subtenant’s obligations hereunder shall terminate, except with respect to any indemnification or hold harmless obligations of Subtenant, which shall survive such termination.
Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.
Landlord’s Default and Tenant’s Remedies In the event Landlord fails to perform its obligations under this Lease, Landlord shall nevertheless not be in default under the terms of this Lease until such time as Tenant shall have first given Landlord written notice specifying the nature of such failure to perform its obligations, and then only after Landlord shall have had thirty (30) days following its receipt of such notice within which to perform such obligations; provided that, if longer than thirty (30) days is reasonably required in order to perform such obligations, Landlord shall have such longer period. In the event of Landlord’s default as above set forth, then, and only then, Tenant may then proceed in equity or at law to compel Landlord to perform its obligations and/or to recover damages proximately caused by such failure to perform (except as and to the extent Tenant has waived its right to damages as provided in this Lease).
Condition of the Premises Tenant acknowledges that, except as expressly set forth in this Lease, neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of the Premises, the Building or the Property, or with respect to the suitability of the Premises, the Building or the Property for the conduct of Tenant’s business. Tenant acknowledges that Landlord shall have no obligation to alter, repair or otherwise prepare the Premises for Tenant’s occupancy or to pay for or construct any improvements to the Premises except as otherwise expressly set forth in this Lease or in the Work Letter attached hereto as Exhibit 3.1. Notwithstanding anything to the contrary contained herein, Landlord represents and warrants to Tenant that (a) upon the Commencement Date, the Building and the Premises will be in material compliance with all Applicable Laws (in each case, without regard for any of the Finish Work, Tenant’s particular use (as opposed to the Permitted Use, generally), or the obligations of any other tenants in the Building with respect to their tenant improvements); (b) Landlord has full power and authority to enter into this Lease and has obtained all consents and taken all actions necessary in connection therewith other than to the extent provided in Section 14.6, below; and (c) upon the Commencement Date, the Building systems provided by Landlord and serving the Premises including electrical, HVAC, plumbing and other utility systems shall be in good working order and condition. Subject to the foregoing and Landlord’s obligation to repair latent defects in the Base Building Work as expressly provided in Section 1.1 of Exhibit 3.1, Tenant’s execution of this Lease and taking of possession of the Premises shall conclusively establish that the Premises, the Building and the Property were at such time in good, sanitary and satisfactory condition and repair; provided, nothing in this sentence relieves Landlord of its obligations pursuant to Section 8.1, below.
Commencement of Term (a) The Premises shall be deemed substantially completed upon the issuance of a certificate of substantial completion by Landlord's architect or a certificate of occupancy by the local building authority, notwithstanding that minor or insubstantial details of construction, mechanical adjustment or decoration remain to be performed. If the substantial completion of the Premises by Landlord is delayed in any way by Tenant or Tenant's Representatives, the Premises shall be deemed substantially completed for purposes of this Section on the date when they would have been substantially completed but for such delay. (b) Tenant's taking possession of the Premises shall be conclusive evidence that the Premises were in good order, condition and repair when Tenant took possession, except for those matters (for which Landlord is responsible as provided in this Lease) of which Tenant gives Landlord notice within 10 days after taking possession. Landlord shall complete or repair such matters as soon as reasonably possible. (c) If Landlord is unable to deliver possession of the Premises to Tenant within 180 days after the Expected Commencement Date (the Outside Commencement Date), then Tenant, as its sole remedy, may terminate this Lease by notice to Landlord given within 10 days after the Outside Commencement Date. The Outside Commencement Date shall be extended by the period of any delay described in Section 1(a). Landlord shall not be liable to Tenant or any third party for its failure to deliver possession of the Premises to Tenant. If the Commencement Date does not occur within one year after the Expected Commencement Date, this Lease shall terminate and Landlord and Tenant shall have no further obligations to the other, except as may otherwise be provided in this Lease. (d) After the Commencement Date has been determined, Landlord and Tenant shall execute a supplemental agreement specifying the Commencement Date, Termination Date and such other information as Landlord shall reasonably require.
Landlord’s Termination Right Whether or not the Premises are affected, Landlord may, by notice to Tenant, within 60 days following the date upon which Landlord receives notice of the Taking of all or a portion of the Real Property, the Building or the Premises, terminate this Lease, provided that Landlord elects to terminate leases (including this Lease) affecting at least 50% of the rentable area of the Building.
Delay of the Substantial Completion of the Premises Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:
Damage or Destruction of Premises If the Premises, the Unit or the Building or any part thereof shall be damaged or destroyed by fire or other casualty (a “casualty”), or ordered to be demolished by the action of any public authority in consequence of a casualty, or taken by any exercise of the right of eminent domain, Tenant shall immediately give notice thereof to Landlord. Unless this Lease is terminated as provided herein, this Lease shall remain in full force and effect and Landlord shall proceed (or shall cause the Primary Board to proceed) with diligence to repair or cause to be repaired such damage so as to restore the Premises, the Building and access thereto, or what may remain thereof (including the Initial Tenant Work but excluding any other Tenant Work), as nearly as practicable to the condition they were in immediately prior to such damage, destruction or taking, subject to then applicable Legal Requirements and Title Matters, but neither Landlord nor the Primary Board shall be required to expend in such repair or rebuilding more than the proceeds of insurance or award of damages, if any, recovered or recoverable with respect to such damage, destruction or taking (plus, in the case of casualty, the amount of any insurance deductibles (which shall be deemed Operating Costs)), less Landlord’s (or the Primary Board’s) reasonable expenses incurred in collecting such proceeds or award, as the case may be, but in the case of damage or destruction only to the extent Landlord was carrying the insurance required to be carried pursuant to this Lease at the time of such damage or destruction. All such repairs made necessary by any negligent act or omission or any willful misconduct of Tenant shall be made by Landlord (or the Primary Board) at Tenant’s expense to the extent that the cost of such repairs is not covered by insurance proceeds available therefor (including the payment by Tenant of any applicable deductible amount). Landlord shall not be liable for delays in the making of any such repairs that are due to Force Majeure, nor shall Landlord be liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting from delays in repairing such damage. All repairs to and replacements of Tenant Property and any Tenant Work other than the Initial Tenant Work shall be made by and at the expense of Tenant, which work Tenant shall promptly commence as soon as practicable and thereafter prosecute diligently to completion.
Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
