Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 323 contracts
Samples: Public Private Partnership, Contract, Professional Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 76 contracts
Samples: Appendix a Draft Contract, Administration Agreement, Cooperative Purchasing Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 64 contracts
Samples: Cooperative Purchasing Agreement, Cooperative Purchasing Agreement, Cooperative Purchasing Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 50 contracts
Samples: Summary Page, Summary Page, Summary Page
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause provisions set forth in paragraph (1.) of this section6(a), the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such the District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause provisions set forth in paragraph (1.a) of this sectionclause, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty 40 hours without payment of the overtime wages required by the clause provisions set forth in paragraph (1.a) of this sectionclause.
Appears in 41 contracts
Samples: Introduction, Introduction, Introduction
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionabove, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section1 above, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (11 above.) of this section.
Appears in 34 contracts
Samples: Project Consultant Agreement, Agreement, Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 32 contracts
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor Contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 29 contracts
Samples: Business Associate Agreement, Agreement, Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 26 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 18 contracts
Samples: Contractor Agreement, Master Agreement, Master Agreement Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (( 1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section...
Appears in 18 contracts
Samples: Services and Funding Agreement, Services and Funding Agreement, A Services and Funding Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionclause, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionclause, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this sectionclause.
Appears in 16 contracts
Samples: Contract, Personal Services Agreement, Construction Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionclause, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionclause, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this sectionclause.
Appears in 14 contracts
Samples: Professional Services Agreement, Professional Services Agreement by And, Consultant Service Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territorysuchterritory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 26 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 12 contracts
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionclause, the contractor Consultant and any subcontractor subconsultant responsible therefor shall be liable for the unpaid wages. In addition, such contractor Consultant and subcontractor subconsultant shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionclause, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this sectionclause.
Appears in 9 contracts
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 9 contracts
Samples: Assistance Agreement (Amyris, Inc.), Assistance Agreement (Amyris, Inc.), Assistance Agreement (Amyris, Inc.)
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such tosuch District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 8 contracts
Samples: Program Agreement, Quality Agreement, Quality Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.paragraph
Appears in 8 contracts
Samples: Administration Agreement, www.omniapartners.com, Administration Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.a) of this section, section the contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this section.
Appears in 7 contracts
Samples: California Government Relations Services Agreement, Event Planning and Production Services Agreement, Professional Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 26 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 7 contracts
Samples: Agreement, Agreement, online.ogs.ny.gov
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to liableto the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect withrespect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionthissection, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 7 contracts
Samples: www.tarrantcountytx.gov, www.tarrantcountytx.gov, www.tarrantcountytx.gov
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.VII(a) of this section, the contractor section Contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and or guards, employed in violation of the clause set forth in paragraph (1.VIII(a) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty (40) hours without payment of the overtime wages required by the clause set forth in paragraph (1.VIII(a) of this section.
Appears in 7 contracts
Samples: General Services Agreement, General Services Agreement, General Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work 5 done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (( 1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 7 contracts
Samples: Form Agreement, Main Agreement, vrapp.vendorregistry.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, the contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph subparagraph (1.) of this sectionparagraph.
Appears in 6 contracts
Samples: Subcontract Form, Attachment 5, Subcontract Form
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionabove, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section1 above, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the ofthe standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (11 above.) of this section.
Appears in 6 contracts
Samples: Master Agreement, Contract for Engineering Services, Project Consultant Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, the contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation violations of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty 40 hours without payment of the overtime wages required by the clause set forth in sub paragraph (1.) of this sectionparagraph.
Appears in 6 contracts
Samples: SRDP 7 Contract, Contract Special Provisions, www.cdbgsc.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, section the contractor Contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 5 contracts
Samples: Assistance Agreement, Assistance Agreement, Assistance Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionclause, the contractor consultant and any subcontractor subconsultant responsible therefor shall be liable for the unpaid wages. In addition, such contractor consultant and subcontractor subconsultant shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionclause, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this sectionclause.
Appears in 5 contracts
Samples: Jacksonville Aviation Authority And, Jacksonville Aviation Authority And, Authority And
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.a) of this section, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this section.
Appears in 5 contracts
Samples: State of Minnesota, State of Minnesota, State of Minnesota
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 5 contracts
Samples: Colorado Construction Agreement, Federal Contracting Requirements, Service Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor Consultant and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor Consultant and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 5 contracts
Samples: CDBG Dr Funded Projects, Agreement, Professional Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, section the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 5 contracts
Samples: Interlocal Agreement, State of Minnesota Grant Contract, Assistance Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionclause, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.paragraph
Appears in 5 contracts
Samples: Professional Services Agreement, Professional Services Agreement, Professional Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 5 contracts
Samples: Special Provisions, Special Provisions, Contract Form Contract
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, section the contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 5 contracts
Samples: Escrow Agreement, Subcontract Agreement, Protective Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionclause, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionclause, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this sectionclause.
Appears in 4 contracts
Samples: Master Services Agreement, Agreement, José Consultant Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of twenty-seven dollars ($10 27) for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 4 contracts
Samples: Emergency Services Agreement, Emergency Services Agreement, Emergency Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 26 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 4 contracts
Samples: www.clpccd.org, www.senate.mn, clpccd.org
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionclause, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionclause, in the sum of $10 29 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this sectionclause.
Appears in 4 contracts
Samples: Agreement, Construction Agreement by and Between, Professional Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.a) of this section, section the contractor Consultant and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor Consultant and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this section.
Appears in 4 contracts
Samples: Federally Funded Projects, Professional Services Agreement, Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.a) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this section.
Appears in 4 contracts
Samples: Agreement, Sample Electrical Restoration Services Contract, facilities.fiu.edu
Violation; liability for unpaid wages; liquidated damages. a. In the event of any violation of the clause set forth in paragraph (1.) of this sectionclause, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionclause, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this sectionclause.
Appears in 4 contracts
Samples: Contract Agreement, Contract Agreement, Contract Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.a) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this section.
Appears in 4 contracts
Samples: purchasing.houstontx.gov, Sample Contract, Sample Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.a)(1) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a)(1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a)(1) of this section.
Appears in 3 contracts
Samples: Professional Services Agreement, Project Finance Agreement, Project Finance Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, the contractor Sub-recipient and any subcontractor Sub-recipient responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor Sub-recipient and subcontractor Sub-recipient shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty 40 hours without payment of the overtime wages required by the clause set forth in sub paragraph (1.) of this sectionparagraph.
Appears in 3 contracts
Samples: Cooperative Endeavor Agreement, Cooperative Endeavor Agreement, Cooperative Endeavor Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionclause, the Consultant, Subconsultant, contractor and or any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such Consultant, Subconsultant, contractor and or subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionclause, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this sectionclause.
Appears in 3 contracts
Samples: Agreement, Agreement For, Agreement For
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, the contractor Contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 3 contracts
Samples: Agreement for Consultant Services, Professional Services Agreement, Agreement for Consultant Services
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.a) of this sectionProvision, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this sectionProvision, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this sectionProvision.
Appears in 3 contracts
Samples: Professional Services Agreement, www.cityofventura.ca.gov, General Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor CONTRACTOR and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor the CONTRACTOR and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this section.
Appears in 3 contracts
Samples: Is an Agreement, Required Clauses, Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, the contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty 40 hours without payment of the overtime wages required by the clause set forth in sub paragraph (1.) of this sectionparagraph.
Appears in 3 contracts
Samples: vhcb.org, www.norwalkct.org, aspirehealthpartners.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, section the contractor AWARDEE and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 3 contracts
Samples: Grant Agreement, Grant Agreement, Grant Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (b) (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (b) (1.) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (b) (1.) of this section.
Appears in 3 contracts
Samples: Master Contract, Master Contract, Master Contract
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor Subrecipient and any subcontractor sub- subrecipient responsible therefor shall be liable for the unpaid wages. In addition, such contractor Subrecipient and subcontractor sub-subrecipient shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 3 contracts
Samples: cams.ocgov.com, cams.ocgov.com, cams.ocgov.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.a) of this section, the contractor Contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this section.
Appears in 2 contracts
Samples: Professional Services Agreement, static1.squarespace.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, section the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 2 contracts
Samples: Contract for Professional Services, Information Technology Service and Support Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 2 contracts
Samples: www.loudoun.gov, vrapp.vendorregistry.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor section Provider and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Provider and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty (40) hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 2 contracts
Samples: Services Agreement, Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.a) of this sectionabove, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this sectionabove, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1a) above.) of this section.
Appears in 2 contracts
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) A of this sectionclause, the contractor Design Professional and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) A of this sectionclause, in the sum of $10 29 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) A of this sectionclause.
Appears in 2 contracts
Samples: Conformed Document, www.tampaairport.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.a) of this section, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, the Contractor and any such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this section, in the sum of $10 29 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this section.
Appears in 2 contracts
Samples: Grant Agreement, Grant Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionabove, the contractor ENGINEER and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor ENGINEER and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section1 above, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (11 above.) of this section.
Appears in 2 contracts
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, the contractor and any subcontractor responsible therefor respon- sible therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph subpara- graph (1.) of this sectionparagraph, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph subparagraph (1.) of this sectionparagraph.
Appears in 2 contracts
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.A) of this section, section the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.A) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.A) of this section.
Appears in 2 contracts
Samples: Attachment a Special, Attachment a Special
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the 20 clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor 21 shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the 22 United States (in the case of work done under contract for the District of Columbia or a territory, to such 23 District or to such territory), for liquidated damages. Such liquidated damages shall be computed with 24 respect to each individual laborer or mechanic, including watchmen and guards, employed in violation 25 of the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which 26 such individual was required or permitted to work in excess of the standard workweek of forty hours 27 without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 2 contracts
Samples: cams.ocgov.com, cams.ocgov.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this ofthis section.
Appears in 2 contracts
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor Consultant and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Consultant and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 2 contracts
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionA above, “Overtime requirements,” the contractor Contractor and any subcontractor Subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor Subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionA, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.A.
Appears in 2 contracts
Samples: Agreement for ________________________________ Services, Agreement for ________________________________ Services
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty 40 hours without payment of the overtime wages required by the clause set forth in sub paragraph (1.) of this sectionparagraph.
Appears in 2 contracts
Samples: Attachment B, www.townoflyons.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, in the sum of $$ 10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph subparagraph (1.) of this sectionparagraph.
Appears in 2 contracts
Samples: www.radresource.net, www.radresource.net
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.. Contractor’s Initials Grantee’s Initials
Appears in 2 contracts
Samples: Seismic Retrofit Grant Program Contractor Agreement, Seismic Retrofit Grants Program Contractor Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.a) of this section, the contractor Contractor and any subcontractor subcontractors responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor subcontractors shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this section, in the sum of twenty-seven dollars ($10 27) for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty (40) hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this section.
Appears in 2 contracts
Samples: cdn5-ss13.sharpschool.com, cdn5-ss13.sharpschool.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), ) for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 2 contracts
Samples: Attachment C Agreement, Written Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, the contractor Construction Manager and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph subparagraph (1.) of this sectionparagraph.
Appears in 1 contract
Samples: Development Block Grants
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, section the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 1 contract
Samples: Memorandum Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor the Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.a) of this section.
Appears in 1 contract
Samples: Professional Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor CONTRACTOR and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor CONTRACTOR and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth f01th in paragraph (1.l) of this section.
Appears in 1 contract
Samples: General Services Contract
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor the Contractor and any subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 1 contract
Samples: Agreement for Temporary
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.ii) of this section, section the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.ii) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.ii) of this section.
Appears in 1 contract
Samples: Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.I) of this section, the contractor section Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 of$ IO for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (( 1.) of this section.
Appears in 1 contract
Samples: c.lakecountyfl.gov
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 31 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 1 contract
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.C)(a) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.C)(a) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.C)(a) of this section.
Appears in 1 contract
Samples: files.covid19.ca.gov
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, section the contractor Contractor and any subcontractor Subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Contractor and subcontractor Subcontractor shall be liable to the United States Citys (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of sumof $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty 40 hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 1 contract
Samples: Standard Contract
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the 21 clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor therefore 22 shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the 23 United States (in the case of work done under contract for the District of Columbia or a territory, to such 24 District or to such territory), for liquidated damages. Such liquidated damages shall be computed with 25 respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of 26 the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which such 27 individual was required or permitted to work in excess of the standard workweek of forty hours without 28 payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 1 contract
Samples: 1 Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of or any violation of the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 1 contract
Samples: Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the 21 clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor 22 shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the 23 United States (in the case of work done under contract for the District of Columbia or a territory, to such 24 District or to such territory), for liquidated damages. Such liquidated damages shall be computed with 25 respect to each individual laborer or mechanic, including watchmen and guards, employed in violation 26 of the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which 27 such individual was required or permitted to work in excess of the standard workweek of forty hours 28 without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 1 contract
Samples: cams.ocgov.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectiona. above, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectiona. above, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) a. of this sectionclause.
Appears in 1 contract
Samples: Extend Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.I) of this section, section the contractor CONTRACTOR and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor the CONTRACTOR and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth fo1th in paragraph (1.a) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth fo1th in paragraph (1.a) of this section.
Appears in 1 contract
Samples: Master Service Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b)(1) of this section, section the contractor Provider and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor the Provider and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b)(1) of this section, in the sum of $10 26 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty fo1iy hours without payment of the overtime wages required by the clause set forth in paragraph (1.b)(1) of this section.
Appears in 1 contract
Samples: Professional Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 of$10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 1 contract
Samples: Price Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of 37 the clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible 38 of 42 1 therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to 2 such District or to such territory), for liquidated damages. Such liquidated damages shall be computed 3 with respect to each individual laborer or mechanic, including watchmen and guards, employed in 4 violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty 5 hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this 6 section.. 7
Appears in 1 contract
Samples: cams.ocgov.com
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor Subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor Subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 1 contract
Samples: dot.ca.gov
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.b) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.b) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.paragraph
Appears in 1 contract
Samples: Williamson County Services Contract
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor Contractor and any subcontractor Subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor Subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of ten dollars ($10 10) for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 1 contract
Samples: dot.ca.gov
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the 17 clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor 18 shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the 19 United States (in the case of work done under contract for the District of Columbia or a territory, to such 20 District or to such territory), for liquidated damages. Such liquidated damages shall be computed with 21 respect to each individual laborer or mechanic, including watchmen and guards, employed in violation 22 of the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which 23 such individual was required or permitted to work in excess of the standard workweek of forty hours 24 without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.. 25
Appears in 1 contract
Samples: Referenced Contract Provisions
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionclause, the contractor Consultant and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor Consultant and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this sectionclause, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this sectionclause.
Appears in 1 contract
Samples: Personal Services Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) 2.A. of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) 2.A. of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) 2.A. of this section.
Appears in 1 contract
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (1.) of this sectionabove, the contractor Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.)) of this sectionabove, in the sum of ten dollars ($10 10) for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty (40) hours without payment of the overtime wages required by the clause set forth in paragraph (1) above.) of this section.
Appears in 1 contract
Samples: Consultant Agreement
Violation; liability for unpaid wages; liquidated damages. In the event of any violation anyviolation of the clause set forth in paragraph (1.a)(1) of this section, section the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.a)(1) of this section, in the sum of $10 27 for each calendar day on which such individual was required or permitted to work in excess of more than the standard workweek of forty hours without payment of the ofthe overtime wages required by the clause set forth in paragraph (1.a)(1) of this section.
Appears in 1 contract
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph subparagraph (1.) of this sectionparagraph.
Appears in 1 contract
Samples: Contract
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, the contractor and any subcontractor responsible therefor therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or r a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph subparagraph (1.) of this sectionparagraph, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph subparagraph (1.) of this sectionparagraph.
Appears in 1 contract
Samples: Long Term Subsidy Contract
Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the 9 clause set forth in paragraph (1.) of this section, section the contractor and any subcontractor responsible therefor 10 shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the 11 United States (in the case of work done under contract for the District of Columbia or a territory, to such 12 District or to such territory), for liquidated damages. Such liquidated damages shall be computed with 13 respect to each individual laborer or mechanic, including watchmen and guards, employed in violation 14 of the clause set forth in paragraph (1.) of this section, in the sum of $10 27 for each calendar day on which 15 such individual was required or permitted to work in excess of the standard workweek of forty hours 16 without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Appears in 1 contract
Samples: ochealthinfo.com