Vacation Schedules (a) Employees shall submit their vacation requests to the supervisor on or before:
Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement.
Vacation Scheduling (a) With the exception of authorized vacation carryover under Clause 18.6, the scheduling and completion of vacations shall be on a calendar-year basis.
NORMAL WORK SCHEDULES 112. Unless otherwise provided in this Agreement, a “normal work day” is a tour of duty of eight (8) hours completed within not more than nine (9) hours. The normal work week for employees covered by this agreement is 40 hours.
Work Schedules Workweeks and work shifts of different numbers of hours may be established by the Employer in order to meet business and customer service needs, as long as the work schedules meet federal and state laws.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Flexible Work Schedules (a) Academic Professional staff members throughout the University may have, as indicated below, flexible work schedules. For example, Academic Professionals often travel on University business and/or work evenings and weekends. A flexible work schedule is defined as having established working hours different from the standard 8:00 a.m. to 5:00 p.m. Monday through Friday schedule, to be followed by an employee for an agreed upon period of time.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Modified Indemnity Where Agreement Involves Design Professional Services Notwithstanding the forgoing, if the services provided under this Agreement are design professional services, as defined by California Civil Code section 2782.8, as may be amended from time to time, the defense and indemnity obligation under Section 1, above, shall be limited to the extent required by California Civil Code section 2782.8.
Changes in Work Schedules (a) In situations other than emergencies, the scheduled employees are entitled to forty-eight (48) hours notice of any change in their respective work schedules.
