Feasibility Study Buyer is granted the right to conduct engineering and/or market and economic feasibility studies of the Property and a physical inspection of the Property, including studies or inspections to determine the existence of any environmental hazards or conditions (collectively, the “Feasibility Study”) during the period (the “Feasibility Period”) commencing on the Effective Date and ending at 5:00 p.m., Central Time, on the June 3, 2010. With Seller’s permission, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours for purposes of analysis or other tests and inspections which may be deemed necessary by Buyer for the Feasibility Study. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property in connection with Buyer’s Feasibility Study; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. Seller agrees to make its representative reasonably available during normal business hours. Buyer will not alter the physical condition of the Property or conduct invasive testing without notifying Seller of its requested tests, and obtaining the written consent of Seller to any physical alteration of the Property or invasive testing. Buyer will utilize commercially reasonable diligence to conduct or cause to be conducted all inspections and tests in a manner and at times which will not unreasonably interfere with any tenant’s use and occupancy of the Property. If Buyer determines, in its sole judgment, that the Property is not suitable for any reason for Buyer’s intended use or purpose, or is not in satisfactory condition, then Buyer may terminate this Contract by written notice to Seller prior to expiration of the Feasibility Period, in which case the Xxxxxxx Money (other than the Option Money) will be returned to Buyer, and neither party shall have any further right or obligation hereunder other than as set forth herein with respect to rights or obligations which survive termination. If this Contract is not terminated pursuant to this Section 5(a), then after expiration of the Feasibility Period, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. If this Contract is not timely terminated pursuant to this Section 5(a), Buyer’s right to terminate this Contract pursuant to this Section 5(a) and any and all objections with respect to the Feasibility Study will be deemed to have been waived by Buyer for all purposes.
Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.
Development Work Do, or cause to be done, such development and other work as may be reasonably necessary to protect from diminution and production capacity of the Mortgaged Property and each producing well thereon.
Development of the Project The Board of Managers shall take such actions as shall be required to cause either the Company or the Management Company (as defined in Section 9(b) below) to perform and complete the construction and other development work as contemplated and/or required under the NVR Purchase and Sale Agreements, or any other construction company selected by the Board of Managers (the “Development Work”), substantially in accordance with the Project Plan, at a cost to the Company not exceeding the total cost set forth in the Budget, in a manner consistent with this Agreement and all applicable laws, ordinances, rules, regulations or requirements (including, without limitation, those with respect to discrimination) of governmental authorities, and in compliance with any covenants, conditions or restrictions affecting all or any portion of the Property.
Completion of the Project (a) The completion of the Project shall be evidenced to the Trustee by a certificate signed by the Project Supervisor on behalf of the User stating that (1) construction of the Improvements has been completed in accordance with the plans and specifications approved by the User, (2) the Equipment has been acquired and installed in accordance with the User's instructions, (3) all Project Costs have been paid, and (4) all facilities and improvements necessary in connection with the Project have been acquired and installed and all costs and expenses incurred in connection therewith have been paid. Notwithstanding the foregoing, such certificate shall state that it is given without prejudice to any rights against any vendor, contractor, subcontractor or other person not a party to this Lease Agreement which exist at the date of such certificate or which may subsequently come into being. The Issuer and the User will cooperate in causing such certificate to be furnished to the Trustee.
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Development and Regulatory Milestones With respect to each of the following milestones, Ikaria shall pay BioLineRx the corresponding payment set forth below within [**] days after the achievement by Ikaria, its Affiliates or Licensees of such milestone: MILESTONE PAYMENT
Phase II The parties acknowledge that this Agreement is not exclusive and GPPC shall have the right to provide consulting services regarding the marketing of the DCC services of Member, GPPC, any of GPPC’s Affiliates, or of any third party, subject to the provisions of Section 5.4 above. During the Term of this Agreement, GPPC may choose to develop the functionality of its own processing platform, or use a third person’s processing platform to enable GPPC to support certain functions in the clearing and settlement of DCC Transactions (“Phase II”). At such time as it is ready to begin implementing Phase II, GPPC shall inform Planet Payment of its plans and the parties shall discuss how Phase II may be integrated into the Acquirer Program. Nothing herein shall prohibit GPPC from implementing Phase II, and Planet Payment agrees that it will use its commercially reasonable efforts to provide assistance to GPPC to implement Phase II, provided that Planet Payment shall not have any obligation whatsoever to assist GPPC in any way in specifying, designing or implementing functions similar to any of Planet Payment’s functions provided hereunder relating to the conversion, calculation, reporting or reconciliation of cross-currency Transactions. Nothing herein shall oblige Planet Payment to disclose, transfer or license any of its IP to GPPC for the purposes of Phase II. Planet Payment shall not charge GPPC for such assistance, unless GPPC requests modifications or enhancements to the Planet Payment Platform to facilitate Phase II, in which case Planet Payment shall only charge GPPC for its actual and out of pocket costs incurred in connection with such modifications or enhancements. The parties shall use good faith efforts to modify the parties’ respective obligations under this Agreement relating to processing of Transactions (but without any change to their respective Revenue Shares) to reflect the reallocation of their respective functions following implementation of Phase II.
Completion of Project The Project shall have been completed per the Plans and Specifications and a Completion Certificate shall have been obtained;
Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
