Train Operator Events of Default The following are Train Operator Events of Default:
Uncontrollable Events BISYS assumes no responsibility hereunder, and shall not be liable for any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control.
Planned Outages Seller shall schedule Planned Outages for the Project in accordance with Good Industry Practices and with the prior written consent of Buyer, which consent may not be unreasonably withheld or conditioned. The Parties acknowledge that in all circumstances, Good Industry Practices shall dictate when Planned Outages should occur. Seller shall notify Buyer of its proposed Planned Outage schedule for the Project for the following calendar year by submitting a written Planned Outage schedule no later than October 1st of each year during the Delivery Term. The Planned Outage schedule is subject to Buyer’s approval, which approval may not be unreasonably withheld or conditioned. Buyer shall promptly respond with its approval or with reasonable modifications to the Planned Outage schedule and Seller shall use its best efforts in accordance with Good Industry Practices to accommodate Xxxxx’s requested modifications. Notwithstanding the submission of the Planned Outage schedule described above, Seller shall also submit a completed Outage Notification Form to Buyer no later than fourteen (14) days prior to each Planned Outage and all appropriate outage information or requests to the CAISO in accordance with the CAISO Tariff. Seller shall contact Buyer with any requested changes to the Planned Outage schedule if Seller believes the Project must be shut down to conduct maintenance that cannot be delayed until the next scheduled Planned Outage consistent with Good Industry Practices. Seller shall not change its Planned Outage schedule without Buyer’s approval, not to be unreasonably withheld or conditioned. Seller shall use its best efforts in accordance with Good Industry Practices not to schedule Planned Outages during the months of July, August, September and October. At Buyer’s request, Seller shall use commercially reasonable efforts to reschedule Planned Outage so that it may deliver Product during CAISO declared or threatened emergency periods. Seller shall not substitute Energy from any other source for the output of the Project during a Planned Outage.
Events If either Party hereto is at any time either during this Agreement or thereafter prevented or delayed in complying with any provisions of this Agreement by reason of strikes, walk-outs, labour shortages, power shortages, fires, wars, acts of God, earthquakes, storms, floods, explosions, accidents, protests or demonstrations by environmental lobbyists or native rights groups, delays in transportation, breakdown of machinery, inability to obtain necessary materials in the open market, unavailability of equipment, governmental regulations restricting normal operations, shipping delays or any other reason or reasons beyond the control of that Party, then the time limited for the performance by that Party of its respective obligations hereunder shall be extended by a period of time equal in length to the period of each such prevention or delay.
Default Events (a) Any material breach of the Funding Agreement by the Recipient, including those set out below, will be an event of default (“Default Event”):
Adverse Events Subsequent to the date hereof, there shall not have occurred any of the following: (i) a suspension or material limitation in trading in securities generally on the New York Stock Exchange, the NASDAQ National Market or the NASDAQ Global Market, (ii) a general moratorium on commercial banking activities in the People’s Republic of China or New York, (iii) the outbreak or escalation of hostilities involving the United States or the People’s Republic of China or the declaration by the United States or the People’s Republic of China of a national emergency or war if the effect of any such event specified in this clause (iii) in your reasonable judgment makes it impracticable or inadvisable to proceed with the public offering or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus, or (iv) such a material adverse change in general economic, political, financial or international conditions affecting financial markets in the United States or the People’s Republic of China having a material adverse impact on trading prices of securities in general, as, in your reasonable judgment, makes it impracticable or inadvisable to proceed with the public offering of the Shares or the delivery of the Shares on the terms and in the manner contemplated in the Prospectus.
Termination Events This Agreement may, by notice given prior to or at the Closing, be terminated:
Extraordinary Events No fault if failure due to an Extraordinary Event
INCLEMENT CONDITIONS Section 1.
Forced Outages During any forced outage, the NYISO or Connecting Transmission Owner may suspend interconnection service to the Interconnection Customer to effect immediate repairs on the New York State Transmission System or the Distribution System. The NYISO shall use Reasonable Efforts to provide the Interconnection Customer with prior notice. If prior notice is not given, the NYISO shall, upon request, provide the Interconnection Customer written documentation after the fact explaining the circumstances of the disconnection.
