Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant as described in Section 12.01 of the Lease or any default by Tenant under this Work Letter (which, for purposes hereof, shall include, without limitation, the delivery by Tenant to Landlord of any oral or written, including electronic, notice instructing Landlord to cease the design and/or construction of the Tenant Improvements and/or that Tenant does not intend to occupy the Premises, and/or any other anticipatory breach of the Lease) has occurred at any time on or before the Substantial Completion of the Premises, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance and/or Landlord may cause Contractor to cease the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 5.01 above), and (ii) all other obligations of Landlord under the terms of this Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to an event of default by Tenant as described in Section 12.01 of the Lease or under this Work Letter (including, without limitation, any anticipatory breach described above in this Section 6.05), then (A) Tenant shall be liable to Landlord for all damages available to Landlord pursuant to the Lease and otherwise available to Landlord at law and/or in equity by reason of a default by Tenant under the Lease or this Work Letter, and (B) Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) Business Days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord (including any portion of the Tenant Improvement Allowance disbursed by Landlord) and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
Lender Default If any Lender shall fail to make any payment required to be made by it pursuant to Section 2.02(c), 2.14(e), 2.17(d), 2.18(d), 2.18(e) or 10.03(c), then the Administrative Agent may, in its discretion (notwithstanding any contrary provision hereof), apply any amounts thereafter received by the Administrative Agent for the account of such Lender to satisfy such Lender’s obligations under such Sections until all such unsatisfied obligations are fully paid.
Landlord Default If Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement or any obligation of Landlord, if any, under any agreement affecting the Leased Property, the performance of which is not Tenant’s obligation pursuant to this Agreement, and any such default shall continue for a period of thirty (30) days after Notice thereof from Tenant to Landlord and any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct the same, Tenant may declare the occurrence of a “Landlord Default” by a second Notice to Landlord and to such Facility Mortgagee. Thereafter, Tenant may forthwith cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys’ fees and court costs) incurred by Tenant in curing the same, together with interest thereon (to the extent permitted by law) from the date Landlord receives Tenant’s invoice until paid, at the Overdue Rate. Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof. If Tenant and Landlord shall fail, in good faith, to resolve any such dispute within ten (10) days after Landlord’s Notice of dispute, either may submit the matter for resolution in accordance with Article 22.
Lease Default Notices To Agent, within 2 Business Days after receipt thereof, copies of (i) any and all default notices received under or with respect to any leased location or public warehouse where Collateral is located, and (ii) such other notices or documents as Agent may reasonably request.
Interest After Event of Default If an Event of Default shall have occurred and is continuing, all sums outstanding and unpaid under the Credit Documents, including this Deed of Trust, shall, at Beneficiary’s option, bear interest at the Default Rate until such Event of Default has been cured. Trustor’s obligation to pay such sums and interest shall be secured by this Deed of Trust.
Guaranty Default Upon the failure of Guarantor to pay the amounts required to be paid hereunder when due following the occurrence of a Tenant Event of Default under the Lease, Landlord shall have the right to bring such actions at law or in equity, including, without limitation, appropriate injunctive relief, as it deems appropriate to compel compliance, payment or deposit, and among other remedies to recover its reasonable attorneys’ fees in any proceeding, including any appeal therefrom and any post judgment proceedings.
Major Default The Purchasers shall be considered to be in “Major Default” in the event that (a) the Purchasers are in breach of their obligations under the Agreement and (b) such breaches, individually or in the aggregate, resulted or would reasonably be expected to result in (i) material Losses to the Sellers or their Affiliates, (ii) material reputational harm to the Sellers or their Affiliates, (iii) material and adverse regulatory consequences to the Sellers or their Affiliates, for which, in each case of clauses (i) through (iii), indemnification by the Purchasers pursuant to Article 8 of the Agreement would not be sufficient to remedy all damages incurred by the Sellers and their Affiliates or (iv) if the Sellers reasonably determine, based on the advice of counsel, that it would reasonably be expected to be a violation of their fiduciary duties under applicable Law to not terminate the Agreement, taking into account the indemnification by the Purchasers pursuant to Article 8 of the Agreement; provided, that the following breaches shall be excluded, and not taken into account, in determining if a Major Default has occurred: (x) any breach to the extent resulting from any action taken by the Purchasers pursuant to and in accordance with written direction given by the Sellers and (y) any breach to the extent arising out of or resulting from, directly or indirectly, a breach by the Sellers of the Agreement, the Transition Services Agreement or the Purchase Agreement.
Owner Default Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perform and complete or comply with the other terms thereof. MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: This bond is subject to the attached Dual Obligee Rider dated [ ]. (Space is provided below for additional signatures of added parties other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY (Corporate Seal) (Corporate Seal) Company: Company: Address: Address: Name and Title: Name and Title: Signature: Signature: (TO BE ATTACHED TO BOND AT TIME OF ISSUANCE) TO BE ATTACHED TO AND FORM PART OF Performance and Payment Bond NO. ___, dated concurrently with the execution of this Rider, issued by the ___, a ___corporation, as Surety, on behalf of Fxxxx, Inc., as Principal, and in favor of ___, as Obligee. IT IS HEREBY UNDERSTOOD AND AGREED that the above described bond(s) are hereby amended to include the following paragraph: Notwithstanding anything contained herein to the contrary, there shall be no liability on the part of the Principal or Surety under this bond to the Obligees, or either of them, unless the Obligees, or either of them, shall make payments to the Principal or to the Surety in case it arranges for completion of the Contract upon default of the Principal, strictly in accordance with the terms of said Contract as to payments, and shall perform all the other obligations required to be performed under said Contract at the time and in the manner therein set forth. IT IS FURTHER UNDERSTOOD AND AGREED that nothing herein contained shall be held to change, alter or vary the terms of the above described bond(s) except as hereinbefore set forth. SIGNED, SEALED AND DATED this ___day of ___, 200_. Fxxxx, Inc. (Contractor) [Name of Project Company] ___ ___,2006 By: [ ] (Surety) By: [Name of Project Company] ___ ___,2006 EXHIBIT J Draw (Payment) Schedule MONTH BILLING TOTAL BILLING 1 $ $ % 2 $ $ % 3 $ $ % 4 $ $ % 5 $ $ % 6 $ $ % 7 $ $ % 8 $ $ % 9 $ $ % 10 $ $ % 11 $ $ % 12 $ $ % 13 $ $ % 14 $ $ % 15 $ $ % 16 $ $ % $[Price] [Name of Project Company] ___ ___,2006 EXHIBIT K Air Emissions Application or Permit [Name of Project Company] ___ ___,2006 EXHIBIT L Phase I and Phase II Engineering Services Agreement [Name of Project Company] ___ ___,2006 L-1 EXHIBIT M Form of Application for Payment [Name of Project Company] ___ ___,2006 M-1 EXHIBIT N Form of Lien Waiver GENERAL CONTRACTOR’S PARTIAL WAIVER OF MECHANIC’S LIEN RIGHTS AND AFFIDAVIT OF DEBTS AND CLAIMS CONDITIONAL LIEN WAIVER STATE: ( INSERT STATE ) FXXXX, INC. COUNTY: ( INSERT COUNTY ) The undersigned is the General Contractor (aka Design-Builder) regarding labor and materials for construction and maintenance work performed for ( INSERT OWNER/PLANT NAME ), at the Facility located at or near ( INSERT PLANT CITY & STATE ) under the terms of a contract. On condition of receiving full payment for bxxxxxxx up to date hereof under the terms of the above mentioned contract, and other good and valuable consideration, the receipt of which is hereby acknowledged, the undersigned does hereby waive and release any and all liens, and any and all claims and rights to lien on the Facility (including all buildings on the premises) under the statutes of the State of ( INSERT STATE ) relating to mechanic’s liens on account of labor and materials furnished by the undersigned up to the date hereof at the Facility, as located on real estate legally described as follows: TRACT 1: ( INSERT LEGAL DESCRIPTION ) TRACT 2: ( INSERT LEGAL DESCRIPTION ) [Name of Project Company] ___ ___,2006 N-1 The undersigned further certifies that all obligations of General Contractor entered into between suppliers/subcontractors and General Contractor regarding this Facility are current as of this date, including all obligations of General Contractor for all work, labor and services performed; materials and equipment furnished; and all known indebtedness and claims against General Contractor for damages arising in any manner in connection with General Contractor’s performance of the contract mentioned above for which General Contractor or property of General Contractor might in any way be held responsible. Dated this ___day of ___, 200___ GENERAL CONTRACTOR: FXXXX, INC. By (Print): Title: (Signature): Witness (Print): (Signature): In the alternative (or if requested): Subscribed and sworn to before me this ___day of ___, 200___. Notary Public My Commission Expires: [Name of Project Company] ___ ___,2006 N-2 EXHIBIT O Form of Consent to Assignment [Name of Project Company] ___ ___,2006
Lease Events of Default The following events shall constitute Lease Events of Default hereunder (whether any such event shall be voluntary or involuntary or come about or be effected by operation of law or pursuant to or in compliance with any judgment, decree or order of any court or any order, rule or regulation of any administrative or governmental body) and each such Lease Event of Default shall be deemed to exist and continue so long as, but only as long as, it shall not have been remedied:
Borrower Default Unless the Administrative Agent shall have received notice from Borrower prior to the date on which any payment is due to the Administrative Agent for the account of the Lenders or the Issuing Bank hereunder that Borrower will not make such payment, the Administrative Agent may assume that Borrower has made such payment on such date in accordance herewith and may, in reliance upon such assumption, distribute to the Lenders or the Issuing Bank, as the case may be, the amount due. In such event, if Borrower has not in fact made such payment, then each of the Lenders or the Issuing Bank, as the case may be, severally agrees to repay to the Administrative Agent forthwith on demand the amount so distributed to such Lender or the Issuing Bank with interest thereon, for each day from and including the date such amount is distributed to it to but excluding the date of payment to the Administrative Agent, at the greater of the Federal Funds Effective Rate and a rate determined by the Administrative Agent in accordance with banking industry rules on interbank compensation.
