Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
Use of Project Development Security Buyer shall be entitled to draw upon the Project Development Security posted by Seller for Daily Delay Damages until such time as the Project Development Security is exhausted. Buyer shall also be entitled to draw upon the Project Development Security for any damages arising upon Buyer’s declaration of an Early Termination Date.
Use of the Equipment 9.1 The Equipment shall be used by Hospital only at the Site and shall not be removed therefrom. Hospital shall use the Equipment only in the regular and ordinary course of Hospital’s business operations and only within the capacity of the Equipment as determined by Elekta’s specifications. Hospital shall not use nor permit the Equipment to be used in any manner nor for any purpose which, in the opinion of Elekta or GKF, the Equipment is not designed or reasonably suitable.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Right to Refuse Dangerous Work An employee shall have the right to refuse to work in situations, which can reasonably be considered dangerous.
Provisioning of High Frequency Spectrum and Splitter Space 3.2.1 BellSouth will provide <<customer_name>> with access to the High Frequency Spectrum as follows:
Application of Miscellaneous Proceeds upon Condemnation, Destruction, or Loss in Value of the Property In the event of a total taking, destruction, or loss in value of the Property, all of the Miscellaneous Proceeds will be applied to the sums secured by this Security Instrument, whether or not then due, with the excess, if any, paid to Borrower. In the event of a partial taking, destruction, or loss in value of the Property (each, a “Partial Devaluation”) where the fair market value of the Property immediately before the Partial Devaluation is equal to or greater than the amount of the sums secured by this Security Instrument immediately before the Partial Devaluation, a percentage of the Miscellaneous Proceeds will be applied to the sums secured by this Security Instrument unless Borrower and Lender otherwise agree in writing. The amount of the Miscellaneous Proceeds that will be so applied is determined by multiplying the total amount of the Miscellaneous Proceeds by a percentage calculated by taking (i) the total amount of the sums secured immediately before the Partial Devaluation, and dividing it by (ii) the fair market value of the Property immediately before the Partial Devaluation. Any balance of the Miscellaneous Proceeds will be paid to Borrower. In the event of a Partial Devaluation where the fair market value of the Property immediately before the Partial Devaluation is less than the amount of the sums secured immediately before the Partial Devaluation, all of the Miscellaneous Proceeds will be applied to the sums secured by this Security Instrument, whether or not the sums are then due, unless Borrower and Lender otherwise agree in writing.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply:
Participating TO's Interconnection Facilities Construction The Participating TO's Interconnection Facilities shall be designed and constructed in accordance with Good Utility Practice. Upon request, within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Participating TO and Interconnection Customer agree on another mutually acceptable deadline, the Participating TO shall deliver to the Interconnection Customer and the CAISO the following “as-built” drawings, information and documents for the Participating TO's Interconnection Facilities [include appropriate drawings and relay diagrams]. The Participating TO will obtain control for operating and maintenance purposes of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades upon completion of such facilities. Pursuant to Article 5.2, the CAISO will obtain Operational Control of the Stand Alone Network Upgrades prior to the Commercial Operation Date.
