The Adjudicator. 9.1.1 Should the Adjudicator resign or die, or should the Procuring Entity and the Service Provider agree that the Adjudicator is not functioning in accordance with the provisions of the Contract; a new Adjudicator will be jointly appointed by the Procuring Entity and the Service Provider. In case of disagreement between the Procuring Entity and the Service Provider, within 30days, the Adjudicator shall be designated by the Appointing Authority designated in the SCC at the request of either party, within 14 days of receipt of such request.
The Adjudicator is the person appointed jointly by the Employer and the Contractor to resolve disputes in the first instance. The Arbitrator is the person appointed to resolve contractual disputes, and as provided for in GCC 27 and 28 hereunder. Bill of Quantities -means the priced and completed Bill of Quantities forming part of the Bid. Compensation Events are those defined in Clause 47 hereunder. The Completion Date is the date of completion of the Works as certified by the Project Manager, in accordance with sub-Clause 58.1. The Contract is the Contract between the Employer and the Contractor to execute, complete, and maintain the Works. It consists of the documents listed in Clause 2.3 below. The Contractor is a person or corporate body who‟s Bid to carry out the Works has been accepted by the Employer. The Contractor's Bid is the completed Bid document submitted by the Contractor to the Employer. The Contract Price is the price stated in the Letter of Acceptance and thereafter as adjusted in accordance with the provisions of the Contract. Days are calendar days; months are calendar months. Day works are varied work inputs subject to payment on a time basis for the Contractor's employees and Equipment, in addition to payments for associated
The Adjudicator. 91.1 The Adjudicator settles the dispute impartially as independent adjudicator and not as arbitrator. His decision is enforceable as a matter of contractual obligation between the Parties and not as an arbitral award. He is paid equally by the Parties.
The Adjudicator. For the purposes of paragraph S8-3 (Adjudication) of Schedule 8 of the Conditions of Contract, the Adjudicator is:- Name: ‘Not Nominated’ Address: .........................................................................................................................
The Adjudicator. 18.1. In any event of dispute between the Lessor and the Lessee (and/or anyone acting on their behalf) regarding matters pertaining to the design, construction and delivery of the Additional Leased Premises, the dispute shall be referred to the decision of the Adjudicator within 7 days of the date of receiving a request from any of the parties. It is clarified that matters brought for the Adjudicator's decision shall relate solely to technical and/or engineering and/or operational matters.
The Adjudicator i. Xxxxx decide the issue of the proper classification for the position based on the existing classification system;
The Adjudicator
