TERMINATION OR SUSPENSION OF THIS AGREEMENT Sample Clauses

TERMINATION OR SUSPENSION OF THIS AGREEMENT. The Owner or Architect/Engineer may terminate this Agreement upon giving written notice to the other that such party has defaulted and failed to fulfill its obligations under this Agreement. The written notice must contain an itemized description and accounting of default and failure. In the event of such default, the Architect/Engineer or Owner shall allow ten (10) calendar days for corrective action or submission of a corrective action plan by the other party. The ten (10) days shall be based upon the date of receipt of the notice by the other party. Should no satisfactory corrective action be taken or acceptable corrective action plan be provided by the defaulting party, the other shall have right to immediately terminate the Agreement through a subsequent written notice of termination. The Owner may terminate this Agreement without cause or for convenience at any time upon giving written notice to the Architect/Engineer. If the Agreement is terminated without cause or for convenience, the Architect/Engineer shall be compensated for all services rendered prior to receiving the written notice. If the Architect/Engineer fails to fulfill his obligations and the Agreement is terminated, the Owner may prosecute the Project to completion by contract or other means available. The Architect/Engineer shall be liable to the Owner for any and all additional costs incurred due to the Architect/Engineer’s failure to perform. The rights and remedies available to the Owner provided herein are in addition to any and all other rights and remedies provided by law or equity. If the Owner fails to make payments to the Architect/Engineer in accordance with this Agreement, such failure shall be considered substantial non-performance and cause for termination subject to the written notice provision above or, at the Architect/Engineer’s option, cause for suspension of performance of services under this Agreement. If the Architect/Engineer elects to suspend services, prior to suspension of services the Architect/Engineer shall also give ten (10) days written notice to the Owner. In the event of a suspension of services, the Architect/Engineer shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. The Architect/Engineer shall resume services upon corrective action or submission of a corrective action plan by the Owner. The Architect/Engineer cannot terminate this Agreement or suspend services if the Project is suspended ...
Sample 1Sample 2
AutoNDA by SimpleDocs
TERMINATION OR SUSPENSION OF THIS AGREEMENT. 1.13.1 The Owner or Architect/Engineer may terminate this Agreement upon giving written notice to the other that such party has defaulted and failed to fulfill its obligations under this Agreement. The written notice must contain an itemized description and accounting of default and failure. In the event of such default, the Architect/Engineer or Owner shall allow ten (10) calendar days for corrective action or submission of a corrective action plan by the other party. The ten (10) days shall be based upon the date of receipt of the notice by the other party. Should no satisfactory corrective action be taken or acceptable corrective action plan be provided by the defaulting party, the other shall have right to immediately terminate the Agreement through a subsequent written notice of termination.
Sample 1Sample 2
TERMINATION OR SUSPENSION OF THIS AGREEMENT. In the event this agreement is terminated, continuity of care will be maintained by other APNs as indicated. Renewal Requirement(s): This agreement shall be officially reviewed, renewed and signed at a minimum of annually from the date of signature. We the undersigned agree to review this document on __Jan 1, 2017_____. By our signatures we agree to follow the parameters specified above. APN: Name: ______Sarah Xxxx, CNM______ Address: ___76 Xxxx 0xx Xx Xxxxxx, XX 55987_________ Phone: ____000-000-0000___________ Signature: __________________________ Date: __________ Medical Director: Name: ______________________________
Sample 1
TERMINATION OR SUSPENSION OF THIS AGREEMENT. ARS may suspend this agreement where the Client has committed a breach of this Agreement or ARS reasonably suspects that the Client has committed a breach or may commit a breach of this Agreement. A breach can include non-payment of invoices, misrepresentation of the services provided to the Client, or the Client becomes insolvent or goes into administration.
Sample 1
TERMINATION OR SUSPENSION OF THIS AGREEMENT. DISH may immediately terminate your Service and this Agreement if you or a user of your account breaches this Agreement or any other agreement between you and DISH. DISH reserves the right in its sole discretion to terminate your account and this Agreement at any time or to suspend (with or without notice) or terminate access to or use of the Service, in whole or in part.
Sample 1
TERMINATION OR SUSPENSION OF THIS AGREEMENT 
Sample 1

Related to TERMINATION OR SUSPENSION OF THIS AGREEMENT

  • Termination of this Agreement (a) The Representative shall have the right to terminate this Agreement by giving notice to the Company as hereinafter specified at any time at or prior to the Closing Date or any Option Closing Date (as to the Option Shares to be purchased on such Option Closing Date only), if in the discretion of the Representative, (i) there has occurred any material adverse change in the securities markets or any event, act or occurrence that has materially disrupted, or in the opinion of the Representative, will in the future materially disrupt, the securities markets or there shall be such a material adverse change in general financial, political or economic conditions or the effect of international conditions on the financial markets in the United States is such as to make it, in the judgment of the Representative, inadvisable or impracticable to market the Shares or enforce contracts for the sale of the Shares (ii) trading in the Company’s Common Stock shall have been suspended by the Commission or Nasdaq or trading in securities generally on the Nasdaq Stock Market, the NYSE or the NYSE MKT shall have been suspended, (iii) minimum or maximum prices for trading shall have been fixed, or maximum ranges for prices for securities shall have been required, on the Nasdaq Stock Market, the NYSE or NYSE American, by such exchange or by order of the Commission or any other governmental authority having jurisdiction, (iv) a banking moratorium shall have been declared by federal or state authorities, (v) there shall have occurred any attack on, outbreak or escalation of hostilities or act of terrorism involving the United States any declaration by the United States of a national emergency or war, any substantial change or development involving a prospective substantial change in United States or other international political, financial or economic conditions or any other calamity or crisis, or (vi) the Company suffers any loss by strike, fire, flood, earthquake, accident or other calamity, whether or not covered by insurance, or (vii) in the judgment of the Representative, there has been, since the time of execution of this Agreement or since the respective dates as of which information is given in the Registration Statement, the Time of Sale Disclosure Package or the Final Prospectus, any material adverse change in the assets, properties, condition, financial or otherwise, or in the results of operations, business affairs or business prospects of the Company, whether or not arising in the ordinary course of business. Any such termination shall be without liability of any party to any other party except that the provisions of Section 5(a)(viii) and Section 7 hereof shall at all times be effective and shall survive such termination.

  • Amendment, Suspension or Termination of the Plan By accepting this Award, Participant expressly warrants that he or she has received an Award of Restricted Stock Units under the Plan, and has received, read and understood a description of the Plan. Participant understands that the Plan is discretionary in nature and may be amended, suspended or terminated by the Company at any time.

  • Duration of this Agreement The Term of this Agreement shall be as specified in Schedule A hereto.

  • TERM AND TERMINATION OF THIS AGREEMENT; NO ASSIGNMENT (a) This Agreement shall go into effect as to the Fund on the date set forth above and shall, unless terminated as hereinafter provided, continue in effect for a period of two years from the date of approval by shareholders of the Fund at a meeting called for the purpose of such approval. This Agreement shall continue in effect thereafter for additional periods not exceeding one (l) year so long as such continuation is approved for the Fund at least annually by (i) the Board of Trustees of the Trust or by the vote of a majority of the outstanding voting securities of the Fund and (ii) the vote of a majority of the Trustees of the Trust who are not parties to this Agreement nor interested persons thereof, cast in person at a meeting called for the purpose of voting on such approval. The terms “majority of the outstanding voting securities” and “interested persons” shall have the meanings as set forth in the 1940 Act;

  • Modification of this Agreement This Agreement may not be modified, nor may compliance with any of its terms be waived, except as noted in Section 11.1, “Notices to Parties,” regarding change in personnel or place, and except by written instrument executed and approved in the same manner as this Agreement. Contractor shall cooperate with Department to submit to the Director of CMD any amendment, modification, supplement or change order that would result in a cumulative increase of the original amount of this Agreement by more than 20% (CMD Contract Modification Form).

  • Application of this Agreement 2.1 All facilities made available by the Bank to any Person in respect of a Card or a Card Account are subject to the terms and conditions of this Agreement (as may be amended from time to time subject to prior notice) and any other applicable terms and conditions. A Person becomes subject to such terms and conditions (if not already so subject) by signing, activating or using a Card or permitting its use.

  • Duration and Termination of this Agreement This Agreement shall remain in force until March 1, 1998, and continue in force from year to year thereafter, but only so long as such continuance is specifically approved at least annually (a) by the vote of a majority of the Trustees who are not parties to this Agreement or interested persons of any party to this Agreement, cast in person at a meeting called for the purpose of voting on such approval, and (b) by the Trustees of the Trust, or by the vote of a majority of the outstanding voting securities of the Fund. The aforesaid requirement that continuance of this Agreement be "specifically approved at least annually" shall be construed in a manner consistent with the 1940 Act and the rules and regulations thereunder and any applicable SEC exemptive order therefrom. This Agreement may be terminated with respect to the Fund at any time, without the payment of any penalty, by the vote of a majority of the outstanding voting securities of the Fund or by the Trust's Board of Trustees on 60 days' written notice to you, or by you on 60 days' written notice to the Trust. This Agreement shall terminate automatically in the event of its assignment. This Agreement may be terminated with respect to the Fund at any time without the payment of any penalty by the Board of Trustees or by vote of a majority of the outstanding voting securities of the Fund in the event that it shall have been established by a court of competent jurisdiction that you or any of your officers or directors has taken any action which results in a breach of your covenants set forth herein.

  • Term and Termination of this Agreement The term of employment of -------------------------------------- Executive (the "Term") pursuant to this Agreement shall commence on the date hereof and shall continue for a term of five (5) years from the date hereof (the "Term").

  • Authorization of this Agreement This Agreement has been duly authorized, executed and delivered by or on behalf of such Selling Stockholder.

Time is Money Join Law Insider Premium to draft better contracts faster.