Termination for Default (Construction Sample Clauses

Termination for Default (Construction. If contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified, or any extension, or fails to complete the work within this time, or if contractor fails to comply with any other provisions of this contract, the recipient may terminate this contract for default. the recipient shall terminate by delivering to contractor a notice of termination specifying the nature of default. In this event, the recipient may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. Contractor and its sureties shall be liable for any damage to the recipient resulting from contractor's refusal or failure to complete the work within specified time, whether or not contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the recipient in completing the work. Contractor's right to proceed shall not be terminated nor shall contractor be charged with damages under this clause if:
Sample 1Sample 2Sample 3See All (35)
AutoNDA by SimpleDocs
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, NYCDOT may terminate this contract for default. NYCDOT shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, NYCDOT may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to NYCDOT resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by NYCDOT in completing the work. The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause if:
Sample 1Sample 2See All (6)
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, the Purchaser may terminate this contract for default. The Purchaser shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the Purchaser may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Purchaser resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Purchaser in completing the work. The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause if:
Sample 1Sample 2
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, SAMTD may terminate this contract for default. SAMTD shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, SAMTD may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to SAMTD resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Recipient in completing the work. The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause if-
Sample 1
Termination for Default (Construction. Section 80-09 of FAA Advisory Circular 150/5370-10 establishes conditions, rights, and remedies associated with Owner termination of this contract due to default of the Contractor.
Sample 1
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will ensure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provision of this contract, City may terminate this contract for default. The City shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the City may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the City resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the City in completing the work. The Contractor's right to proceed shall not be terminated nor shall the Contractor be charged with damages under this clause if: 1. The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of City, acts of another contractor in the performance of a contract with City, epidemics, quarantine restrictions, strikes, freight embargoes; and 2. The Contractor, within [10] days from the beginning of any delay, notifies City in writing of the causes of delay. If, in the judgment of City, the delay is excusable, the time for completing the work shall be extended. The judgment of City shall be final and conclusive for the parties, but subject to appeal under the Disputes clause(s) of this contract. If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of City.
Sample 1
Termination for Default (Construction. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, the county may terminate this contract for default. The County shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the County may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the County resulting from the Contractor’s refusal or failure to complete the work within the specified time, whether or not the Contractor’s right to proceed with the work is terminated. This liability includes any increased costs incurred by the County in completing the work. The Contractor’s right to proceed shall not be terminated nor the Contractor charged with damages under this clause if:
Sample 1
AutoNDA by SimpleDocs

Related to Termination for Default (Construction

  • Termination for Default; Remedies 8.2.1 Each of the following shall constitute an immediate event of default (“Event of Default”) under this Agreement:

  • Termination for Default The County may, by written notice to the Contractor terminate this contract for default in whole or in part (delivery orders, if applicable) if the Contractor fails to:

  • H DEFAULT, DISRUPTION AND TERMINATION H1 Termination on insolvency and change of control H1.1 The Client may terminate the Contract with immediate effect by notice in writing where the Contractor is a company and in respect of the Contractor:

  • SUSPENSION & TERMINATION FOR DEFAULT Enterprise Services may suspend Contractor’s operations under this Master Contract immediately by written cure notice of any default. Suspension shall continue until the default is remedied to Enterprise Services’ reasonable satisfaction; Provided, however, that, if after thirty (30) days from such a suspension notice, Contractor remains in default, Enterprise Services may terminate Contractor’s rights under this Master Contract. All of Contractor’s obligations to Enterprise Services and Purchasers survive termination of Contractor’s rights under this Master Contract, until such obligations have been fulfilled.

  • Default Remedies Termination A. [Sec. 400]

  • Erroneous Termination for Default If, after notice of termination of Vendor’s right to proceed under the provisions of this clause, it is determined for any reason that the contract was not in default, or that the delay was excusable under the provisions of the prior paragraph (Excuse for Nonperformance or Delayed Performance), the rights and obligations of the parties shall be the same as if the notice of termination had been one of termination for convenience.

  • Termination for Concessionaire Default 37.1.1 Save as otherwise provided in this Agreement, in the event that any of the defaults specified below shall have occurred, and the Concessionaire fails to cure the default within the Cure Period set forth below, or where no Cure Period is specified, then within a Cure Period of 60 (sixty) days, the Concessionaire shall be deemed to be in default of this Agreement (the “Concessionaire Default”), unless the default has occurred solely as a result of any breach of this Agreement by the Authority or due to Force Majeure. The defaults referred to herein shall include:

  • Default Events and Termination 18.1 Each of the following circumstances shall constitute a General Default:

  • Performance Default and Remedies Subsection B. DEFAULT AND REMEDIES, second paragraph of the Contract is modified as follows (underlined language is added and stricken language is deleted): “Written notice of default and a reasonable 30-day opportunity to cure must be issued by the party claiming default.”

  • Termination Remedies Section E.1.

Time is Money Join Law Insider Premium to draft better contracts faster.