Tenant Contractor Sample Clauses

Tenant Contractor. Any independent contractor of Tenant (or any employee or agent of Tenant) performing Tenant’s Initial Construction shall be a “Tenant Contractor” and shall be subject to all of the terms, conditions and requirements contained in the Lease. The identity and qualifications of each Tenant Contractor shall be subject to Landlord’s prior written approval, which shall not be unreasonably withheld, conditioned, or delayed. Without limitation, Tenant shall require each Tenant Contractor to adjust and coordinate Tenant’s Initial Construction to meet the schedule or requirements of other work being performed by or for Landlord throughout the Building. Tenant shall insure that each Tenant Contractor shall take all reasonable steps to assure that any work is carried out without disruption from labor disputes arising from whatever cause, including, without limitation, disputes concerning union jurisdiction and the affiliation of workers employed by said Tenant Contractor or its subcontractors. Tenant shall be responsible for, and shall reimburse Landlord for, all costs and expenses, including, without limitation, attorney’s fees incurred by Landlord in connection with any breach by the contractor of such obligations. At all times while performing Tenant’s Initial Construction, Tenant and each Tenant Contractor shall not discriminate against any individual because of race, color, sex, religion or national origin and will, as may be required by the municipality in which the Building is located or any other public authority having jurisdiction, comply with all applicable laws, regulations and equal opportunity policies generally adhered to by comparable office buildings in the same geographic area as the Building. In all events, Tenant shall indemnify the Indemnitees in the manner provided in Section 5.5.1 of this Lease against any claim, loss or cost arising out of any interference with, or damage to, any work in the Building being done by Landlord, or any delay thereto, or any increase in the cost thereof on account in whole or in part of any act, omission, neglect or default by Tenant or any Tenant Contractor in the performance of Tenant’s Initial Construction.
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
Tenant Contractor. Except as set forth in the Lease, NO WORK SHALL BE DONE ON THE PREMISES BY TENANT UNTIL LANDLORD HAS APPROVED TENANT’S PLANS AND CONTRACTOR IN WRITING. In instances where Tenant Improvements may coincide with construction by Landlord or other tenants, Tenant’s contractor shall work in conjunction with other contractors so that Tenant’s contractor does not interfere or delay the construction process of others in the Building. Tenant’s contractor must perform the work in such a manner as not to cause harm to others’ on-going construction, delay the progress of such work or create conflicts with labor organizations. Landlord reserves the right to cause the removal of the Tenant’s contractor if any such labor problems arise. Tenant’s contractor must keep the area, HVAC system and restrooms clean and free of dust and debris, with a minimum of noise and interruption to the Common Areas of the Development. Tenant’s contractor is responsible for keeping interior and exterior areas clean of construction debris at all times. If the Tenant contractor fails or refuses to keep these areas clean at all times, Landlord reserves the right to clean these areas at Tenant’s expense. Tenant’s contractor shall erect temporary partitions, dust barriers, etc. as required by Landlord to minimize impact of construction activities on the common areas of the Development.
Sample 1
Tenant Contractor. Any contractor of Tenant (or any employee or agent of Tenant) performing Tenant’s Initial Construction shall be subject to all of the terms, conditions and requirements contained in the Lease. Landlord shall have the right to review and approve the contract between Tenant and the general contractor performing Tenant’s Initial Construction, such approval not to be unreasonably withheld, conditioned or delayed.
Sample 1

Related to Tenant Contractor

  • Contractor A contractor designated by Landlord (the “Contractor”) shall perform the Tenant Improvement Work. In addition, Landlord may select and/or approve of any subcontractors, mechanics and materialmen used in connection with the performance of the Tenant Improvement Work.

  • Tenant’s Contractors If Tenant should desire to enter the Premises or authorize its agent to do so prior to the Commencement Date of the Lease, to perform approved work not requested of the Landlord, Landlord shall permit such entry if:

  • General Contractor The general contractor reasonably selected by Landlord with respect to Landlord's TI Work. Tenant shall have no right to direct or control such General Contractor.

  • Tenant’s Work During the Term Tenant may not perform any work, alterations, installations, additions, improvements, structural repairs or restorations to the Property (“Tenant’s Work”) without the prior written consent of Landlord which (i) in the case of alterations, additions, installations or improvements of a structural nature or involving the Building systems, may be granted or withheld by Landlord in its sole and absolute discretion and (ii) in the case of alterations or improvements of a non-structural nature or not involving Building systems, shall not be unreasonably withheld or delayed. In connection with such consent, Tenant shall submit to Landlord such detailed plans, specifications, drawings and other materials reasonably requested by Landlord. Tenant may make such non-structural alterations and perform work of a decorative nature without Xxxxxxxx’s prior written consent. At Tenant’s sole cost, Xxxxxxxx agrees to cooperate with Xxxxxx (including signing applications) in obtaining any necessary permits for any Tenant’s Work that Xxxxxx is permitted to make hereunder. In all cases the Tenant’s Work shall be performed at Tenant’s sole cost and expense and by contractors selected by Xxxxxx. Tenant agrees that the Tenant’s plans and specifications shall be in compliance with applicable laws, rules and regulations, that Tenant shall not commence construction until it obtains (if required) a building permit for Tenant’s Work, and that such Tenant’s Work shall be performed in accordance with the building permit, in compliance with applicable law and in accordance with the Tenant’s plans and specifications. As a condition of approving such Tenant's Work the Landlord may require the Tenant to maintain such additional insurance coverages (in addition to those required in Article 8 hereof) as the Landlord may reasonably require.

  • Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.

  • Tenant Tenant shall, at Tenant's expense, obtain and keep in force at all times the following insurance:

  • Lessee The related Lessee is a Person other than MBFS USA, any Affiliate thereof or a Governmental Authority and, at the time of origination of the 201[__]-[__] Lease, based on information provided by the Lessee, the Lessee is located in and has a billing address within a State.

  • LANDLORD The covenants and obligations contained in this Lease on the part of Landlord are binding on Landlord, its successors, and assigns only during their respective period of ownership of an interest in the Building. In the event of any transfer or transfers of such title to the Building, Landlord (and, in the case of any subsequent transfers or conveyances, the then grantor) shall be concurrently freed and relieved from and after the date of such transfer or conveyance, without any further instrument or agreement, of all liability with respect to the performance of any covenants or obligations on the part of Landlord contained in this Lease thereafter to be performed.

  • THE WORK The term "

  • Contractors and subcontractors shall establish and maintain a written sexual harassment policy and shall inform their employees of the policy. The policy must contain a notice that sexual harassment will not be tolerated and employees who practice it will be disciplined.

Time is Money Join Law Insider Premium to draft better contracts faster.