TEMPORARY SUSPENSION OF THE WORK Sample Clauses

TEMPORARY SUSPENSION OF THE WORK. The Owner shall have the authority to suspend the work wholly, or in part, for such period or periods as he may deem necessary, due to unsuitable weather, or such other conditions as are considered unfavorable for the prosecution of the work, or for such time as is necessary due to the failure on the part of the Contractor to carry out orders given or perform any or all provisions of the contract. In the event that the Contractor is ordered by the Owner , in writing, to suspend work for some unforeseen cause not otherwise provided for in the contract and over which the Contractor has no control, the Contractor may be reimbursed for actual money expended on the work during the period of shutdown. No allowance will be made for anticipated profits. The period of shutdown shall be computed from the effective date of the Owner 's order to suspend work to the effective date of the Owner 's order to resume the work. Claims for such compensation shall be filed with the Owner within the time period stated in the Owner 's order to resume work. The Contractor shall forward his/her claim information substantiating the amount shown on the claim to the Owner for consideration in accordance with local laws or ordinances. No provision of this article shall be construed as entitling the Contractor to compensation for delays due to inclement weather, for suspensions made at the request of the Contractor, or for any other delay provided for in the contract, plans, or specifications. If it should become necessary to suspend work for an indefinite period, the Contractor shall store all materials in such manner that they will not become an obstruction nor become damaged in any way. The Contractor shall take every precaution to prevent damage or deterioration of the work performed and provide for normal drainage of the work. The Contractor shall erect temporary structures where necessary to provide for traffic on, to, or from the Airport.
Sample 1Sample 2Sample 3See All (27)
AutoNDA by SimpleDocs
TEMPORARY SUSPENSION OF THE WORK. (a) The Work or any portion of the Work may be temporarily suspended by the Owner immediately upon written notice to the Prime Contractor for any reason, including but not limited to:
Sample 1Sample 2Sample 3See All (11)
TEMPORARY SUSPENSION OF THE WORK i. The Principal Representative shall have the authority to suspend the Work (each a “Suspension of Work”), either wholly or in part, for such period or periods as it may deem necessary due to:
Sample 1Sample 2

Related to TEMPORARY SUSPENSION OF THE WORK

  • Temporary Suspension 13.1. JetBrains reserves the right to suspend Customer’s access to JetBrains Products if:

  • Temporary Work 17.01 (a) Employees shall perform any temporary work which the Management directs with the understanding that when an employee is assigned to a job with a lesser rate of pay, he shall receive his regular rate of pay.

  • Temporary Services The steamfitters shall not do any other work and shall not be permitted to work more than one shift in a twenty- four hour day. When steamfitters are present during the regular working day, no temporary services steamfitter will be required. Effective Period: 7/1/2015 - 6/30/2016 Wage Rate per Hour: $41.80 Supplemental Benefit Rate per Hour: $42.76 Overtime Double time the regular rate after an 8 hour day. Double time the regular time rate for Saturday. Double time the regular rate for Sunday.

  • Temporary Upgrade An employee in a temporary upgrade status shall have no right to grieve or arbitrate release from such temporary upgrade status.

  • Temporary Upgrading (a) In the event that an employee is temporarily transferred to a higher classification than that to which the employee is regularly assigned, he or she shall be paid at the normal wage scale for such higher classification during the period of such transfer for not less than a full tour of duty.

  • Temporary Vacancy A vacancy in a position caused by the regularly assigned occupant being absent from duty (including on vacation but excluding pre-retirement vacation) or temporarily assigned to other duties.

  • Temporary Structures Installation of temporary construction-related structures including scaffolding, barriers, screening, fences, protective walkways, signage, office trailers or restrooms.

  • Temporary Layoff The Employer may temporarily layoff an employee for up to ninety (90) days due to an unanticipated loss of funding, revenue shortfall, lack of work, shortage of material or equipment, or other unexpected or unusual reasons. An employee will normally receive seven (7) days notice of a temporary layoff.

  • Temporary Facilities a. The Contractor shall obtain permits for, install and maintain in safe condition all scaffolds, hoisting equipment, barricades, walkways, or other temporary structures that may be required to accomplish the work. Such structures shall be adequate for the intended use and capable of safely accepting all loads that may be imposed upon them. They shall be installed and maintained in accordance with all applicable codes and regulations.

  • Temporary Layoffs A. The Employer may initiate a temporary layoff for up to twelve (12) working days per fiscal year. Employees will be given thirty (30) days’ notice before the effective date of a temporary layoff. Employees may request alternative temporary layoff days from their manager or supervisor and any requests will be considered and approved or denied in writing.

Time is Money Join Law Insider Premium to draft better contracts faster.