Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide the Contractor written notice outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Suspension of Works 24.1 Where the Contract is subject to the Construction Contracts Act 2002, the Client hereby expressly acknowledges that:
Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:
Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.
Suspension of Work and Termination 15.01 Owner May Suspend Work
Cessation of Work Any one or all employees working in the immediate proximity when a fatal accident has occurred may without discrimination refrain from working the balance of the shift.
TERMINATION OR SUSPENSION OF SERVICES Return of Data The Contractor shall return Data in a format agreed upon within the Authorized User Agreement or as agreed to with the Authorized User. This can, if specified within the Authorized User Agreement, be carried out by providing an application programmable interface or other such efficient electronic tools. The Contractor must certify that all Data has been removed from its system and removed from backups within timeframes established in the Authorized User Agreement or as agreed to with the Authorized User. Suspension of Services During any period of suspension of service, the Authorized User shall have full access to all Data at no charge. This can, if specified within the Authorized User Agreement, be carried out by providing an application programmable interface or other such efficient electronic tools. The Contractor shall not take any action to erase and/or withhold any Authorized User Data, except as directed by the Authorized User. Expiration or Termination of Services Upon expiration or termination of an Authorized User Agreement, the Authorized User shall have full access to all Data for a period of 60 calendar days. Unless noted in the original Authorized User Agreement, this period will be covered at no charge. This can, if specified within the Authorized User Agreement, be carried out by providing application programmable interface or other such efficient electronic tools. During this period, the Contractor shall not take any action to erase and/or withhold any Data, except as directed by the Authorized User. An Authorized User shall have the right to specify a period in excess of 60 calendar days in its RFQ. RESERVED RESERVED
Suspension of Services We have the right to suspend the benefit of any Credit Union service at any time for reasonable cause. At Our discretion, We also have the right to pay any share draft presented for payment from Your Account after Your Account is closed or suspended and to recover such amount paid from You. Account services are available to those members in good standing with the Credit Union. We reserve the right to cancel or suspend services to a member who is not in good standing, which includes members that have: (a) a delinquent loan; (b) a primary Share Account balance below the $25.00 minimum; (c) an unresolved deposited returned check; (d) any unpaid and uncollected fees; or (e) a negative balance on an Account. ASSIGNABILITY. You may not assign or transfer any interest in Your Account.
