Suspension by Owner. Should the Owner postpone or delay the Project or otherwise suspend performance of this Agreement for a longer period than has been allowed in the Agreement form, the Architect may terminate the Agreement by written notice to the Owner and the Architect shall be paid for Services rendered.
Suspension by Owner. Should the Owner suspend its agreement with the Contractor or any part which includes the Subcontract Work, the Contractor shall notify the Subcontractor in writing and upon receiving notification the Subcontractor shall immediately suspend the Subcontract Work. In the event of Owner suspension, the Contractor's liability to the Subcontractor shall be limited to the extent of the Contractor's recovery on the Subcontractor's behalf under the Subcontract Documents. The Contractor agrees to cooperate with the Subcontractor, at the Subcontractor's expense, in the prosecution of any Subcontractor claim arising out of an Owner suspension and, in the Contractor’s sole discretion, to permit the Subcontractor to prosecute the claim, in the name of the Contractor, for the use and benefit of the Subcontractor.
Suspension by Owner. Should the Owner suspend the Work or any part which includes the Subcontract Work and such suspension is not due to any act or omission of the Contractor, or any other person or entity for whose acts or omissions the Contractor may be liable, the Contractor shall notify the Subcontractor in writing and upon receiving notification the Subcontractor shall immediately suspend the Subcontract Work. In the event of Owner suspension, the Contractor's liability to the Subcontractor shall be limited to the extent of the Contractor's recovery on the Subcontractor's behalf under the Subcontract Documents. The Contractor agrees to cooperate with the Subcontractor, at the Subcontractor's expense, in the prosecution of any Subcontractor claim arising out of an Owner suspension and to permit the Subcontractor to prosecute the claim, in the name of the Contractor, for the use and benefit of the Subcontractor.
Suspension by Owner. 8.3.1 The Contracting Officer may order Contractor in writing to suspend, delay or interrupt all or any part of the Work for such period as it may determine to be appropriate for the convenience of Owner.
Suspension by Owner. Owner may order Construction Manager to suspend, delay or interrupt the Work, in whole or in part, for any reason and for such period of time as Owner may determine. Upon resumption of the Work, an adjustment shall be made for any reasonable increases in the cost of performance of the Work substantiated by Construction Manager to Owner, including profit on the increased cost of performance resulting from the suspension, delay or interruption ordered by Owner. However, no adjustment shall be made to the extent: (1) that performance is, was or would have been so suspended, delayed or interrupted by another cause for which Construction Manager is responsible; or (2) that an equitable adjustment is made or denied under another provision of the Contract Documents (except as to costs and expenses paid by Construction Manager to its Subcontractors and materialmen).
Suspension by Owner. Should the Owner suspend the Owner-Contractor Agreement or any part of the Owner-Contractor Agreement which includes the Subcontractor's Work, the Contractor shall so notify the Subcontractor in writing and upon receipt of said notice the Subcontractor shall immediately suspend the Subcontractor's Work. In the event of such Owner suspension, the Contractor's liability to the Subcontractor is limited to the extent of the Contractor's recovery on the Subcontractor's behalf under the Contract Documents. The Contractor agrees to cooperate with the Subcontractor, at the Subcontractor’s expense, in the prosecution of any Subcontractor claim arising out of an Owner's suspension and to permit the Subcontractor to prosecute said claim, in the name of the Contractor, for the use and benefit of the Subcontractor.
Suspension by Owner. Should Owner suspend its Prime Contract with CH2M HILL or any part which includes Subcontractor’s Work, CH2M HILL shall notify Subcontractor in writing and upon receiving notification Subcontractor shall immediately suspend Subcontractor’s Work. In the event of Owner suspension, CH2M HILL’s liability to Subcontractor shall be limited to the extent of CH2M HILL’s recovery on Subcontractor’s behalf under the Contract Documents.
Suspension by Owner. The Work may be suspended by the Owner as provided in Article XIV of the General Conditions.
Suspension by Owner. Owner may suspend the Project at its sole discretion. If the Project is suspended by Owner for more than 30 consecutive days, A/E shall be compensated for services performed prior to the notice of suspension, provided the suspension was not caused by A/E’s negligence or wrongful act. A/E’s compensation shall be equitably adjusted to provide for expenses incurred in the interruption and resumption of A/E’s services. Upon written notice by Owner to resume services, A/E shall promptly continue with its responsibilities under this Agreement. In the event of termination or suspension as provided for above, all construction drawings, sketches, renderings, models, other reproducible drawings, surveys, reports, photographs, calculations, prepared by A/E under this Agreement, copies of all correspondence and papers received or issued by A/E and all equipment and publications authorized by Owner for purchase shall be delivered to Owner upon request and Owner shall have the same rights to their use as if the termination or suspension had not occurred, provided, however, that A/E has been compensated according to this article.
Suspension by Owner. Owner may, upon written notice to Construction Manager, require Construction Manager to suspend, delay or interrupt the Work, in whole or in part, for any reason including, without limitation, the issuance of an order by a court or other public authority having jurisdiction or the enactment of any law, regulation or rule prohibiting the completion of the Project, for such period of time as may be directed by Owner. Notwithstanding the foregoing, if the Work is suspended in accordance with this Section 9.3 for a period of ninety (90) days or more, Construction Manager may, on written notice to Construction Manager, terminate this Agreement.
