Special penalties Sample Clauses

Special penalties. Because of the significance of the works, are burdened, without the need for notice and by the breach only, with a daily penalty of EUR 250 for every calendar day of non-performance: Non-delivery of administrative and technical documents such as reports: because not having delivered the documents listed by the time set during construction site meetings or by administrative order. Absence from construction site meetings or coordination meetings: For every absence a penalty will be imposed to the building contractor who has not attended or has not been validly represented at meetings which he was supposed to attend. Delay in executing observations or administrative orders of the contracting authority via the managing official: Where the lists of observations result from construction site visits, in particular for painting orders, or upon acceptance, have not been fulfilled by the time set by the managing official, the contractor will be penalised per calendar day of delay until performance is effectively carried out. Change of one of the key staff members without prior agreement of the contracting authority: A lump sum penalty is applied per day of default, ending when, either the managing official obtains the approval of the contracting authority for the new member’s being put in place, or the replaced member is re-established in its duties, or both parties agree about a new person as a replacement that is jointly accepted. When the penalties are applied, these may in no case be recuperated retrospectively, even where agreement is found. If a shortcoming to one of the stipulations mentioned above is found in accordance with Article 44 §2 of the Royal Decree of 14 January 2013, the contracting authority may allow a period to the building contractor to repair the shortcoming and to inform it about this reparation by registered mail. In this case, the contractor is notified of the deadline along with the failure of performance report mentioned in Art. 44 §2 of the Royal Decree of 14 January 2013. If no term is indicated in the registered letter the contractor is to repair the shortcomings without any further delay.
Sample 1
AutoNDA by SimpleDocs
Special penalties. TYPE OF PENALTY AMOUNT I COP 560,000 II COP 1,120,000
Sample 1Sample 2
Special penalties. The following special penalty provisions shall apply to violations of these Sanitary Sewer chapters:
Sample 1

Related to Special penalties

  • - FINANCIAL PENALTIES By virtue of the Financial Regulation applicable to the general budget of the European Communities, any beneficiary declared to be in grave breach of his obligations shall be liable to financial penalties of between 2% and 10% of the value of the grant in question, with due regard for the principle of proportionality. This rate may be increased to between 4% and 20% in the event of a repeated breach in the five years following the first. The beneficiary shall be notified in writing of any decision by the Commission to apply such financial penalties.

  • Shift Penalties (1) In addition to an employee’s ordinary salary (including higher duties allowance), the employee is entitled to the highest penalty rate for shiftwork that applies to the performance of shiftwork set out in the following table: Rostered time of ordinary duty Penalty rate (% of employee’s hourly rate of salary) Ordinary duty, any part being between 6:00 pm and 6:30 am 15% Ordinary hours worked continuously for a period exceeding 4 weeks on a shift falling wholly within the period from 6:00 pm to 8:00 am 30% Ordinary duty, Saturday 50% Ordinary duty, Sunday 100% Ordinary duty, public holiday 150%

  • Criminal Penalties Any individual director, officer, or employee of the contractor or of its subcontractors and suppliers who are indemnified under the provisions of this clause are subject to criminal penalties, pursuant to section 223(c) of the Act, for knowing and willful violation of the Atomic Energy Act of 1954, as amended, and applicable DOE nuclear safety-related rules, regulations or orders which violation results in, or, if undetected, would have resulted in a nuclear incident.

  • Statutory Penalties The defendant understands that upon his plea of guilty to Count One of the indictment charging him with conspiracy, the maximum penalty the Court may impose is not more than five years of imprisonment, a $250,000.00 fine, three years of supervised release, an order of restitution, and a $100.00 mandatory special assessment which must be paid in full at the time of sentencing. The defendant further understands that this offense is a Class D felony.

  • Prepayment Penalties 4. Any provisions in your consumer credit contract, loan, security, or account agreements that are determined to be inconsistent with or contradictory to these disclosures or the MLA (as they may be changed or amended from time to time) are inapplicable with regard to this loan. However, all other terms and conditions of the consumer credit contract shall remain in full force and effect.

  • Forecasting Penalties The Forecasting Penalty shall be equal to the greater of (A) one hundred fifty percent (150%) of the Contract Price or (B) the absolute value of the Real-Time Price, in each case for each MWh of Energy Deviation outside the Performance Tolerance Band, or any portion thereof, in every hour for which Seller fails to meet the requirements in Section 4.6(c)(i). Settlement of Forecasting Penalties shall occur as set forth in Section 6.1 of this Agreement.

  • Civil Penalties The contractor and its subcontractors and suppliers who are indemnified under the provisions of this clause are subject to civil penalties, pursuant to section 234A of the Act, for violations of applicable DOE nuclear- safety related rules, regulations, or orders. If the contractor is a not-for-profit contractor, as defined by section 234Ad.(2), the total amount of civil penalties paid shall not exceed the total amount of fees paid within any 1-year period (as determined by the Secretary) under this contract.

  • CONTRACTUAL PENALTIES 1. Should the Accommodated Person fail to pay the price for the accommodation in the agreed amount, by the due date and under the correct variable symbol, he/she is obliged to pay interest on late payments under Section 10(2) of Act No. 176/2004 Coll., on the Disposal of the Property of Public Institutions and the Amendment to Act No. 259/1993 of the National Council of the Slovak Republic, on the Slovak Forestry Chamber, as amended by Act No. 464/2002 Coll., as amended. In addition, he/she is obliged to pay a contractual penalty (even if the contractual obligations are breached not through a fault of the Accommodated Person, e.g., by error of the financial institution) in the amount of 0.3 % of the amount due for each day of delay. The agreement regarding the contractual penalty shall not affect the Landlord’s entitlement to demand compensation for damages. Both entitlements can be exercised by the Landlord concurrently. Both the contractual penalty and the interest on late payments are to be paid via a separate bank transfer to the Landlord’s account stated in Article I in the “Landlord” section hereof (separately from the price for the accommodation).

  • Maximum Statutory Penalties 8. Defendant understands that the charge to which he is pleading guilty carries the following statutory penalties:

  • Interest; Penalties In the event the Company or any Sponsor Affiliate should fail to make any of the payments to the County required under this Fee Agreement, then the item or installment so in default shall continue as an obligation of the Company or such Sponsor Affiliate until the Company or such Sponsor Affiliate shall have fully paid the amount, and the Company and any Sponsor Affiliates agree, as applicable, to pay the same with interest thereon at a rate, unless expressly provided otherwise herein and in the case of FILOT payments, of 5% per annum, compounded monthly, to accrue from the date on which the payment was due and, in the case of FILOT payments, at the rate for non-payment of ad valorem taxes under State law and subject to the penalties the law provides until payment.

Time is Money Join Law Insider Premium to draft better contracts faster.