Section Schedule General Requirements Sample Clauses

Section Schedule General Requirements. As part of the SMP and a component part of the Administration Plan, the Section Schedule shall be created and used for planning and monitoring the progress of the Section Work. The purpose of the Section Schedule is to ensure adequate planning, scheduling, and resource allocations occur to provide a reasonable and executable work Plan, cash flow projections, and continuous monitoring and reporting for Work performed or remaining. The Section Schedule shall also be used for coordinating the Work, identifying Work to be performed, evaluating changes, and as a tool for measuring and communicating progress. The Baseline Schedule, the Revised Baseline Schedule, Monthly Schedule Updates, and Recovery Schedules are collectively referred to as the Section Schedules. All Section Schedules shall be in accordance with the following guidelines: · be generated and developed in accordance with the guidance of “Part 7.2—Schedule Planning and Development” of the Association for the Advancement of Cost Engineering’s (“AACE”) Total Cost Management Framework and the associated Recommended Practices; · apply the Critical Path Method of network calculation to generate the schedule (the Critical Path shall be based on the longest network path through the Work) and prepare the schedule using the Precedence Diagram Method to establish relationships and interdependencies between the individual activities required to complete the Work; · specify the longest path for defining critical activities and care shall be taken to distinguish between the Critical Path and near-Critical Paths; · be compatible with MDOT’s scheduling software (currently Primavera P6) and implement any new operating practices as a result of MDOT’s amendments to any such software, standards, and procedures throughout the life of the Section P3 Agreement; · use scheduling software with the capability to import and export data in the Primavera Proprietary Exchange Format (“XER”); · include a WBS, the development of which is based on a Deliverable-oriented methodology capturing all the Section activities and has each schedule activity mapped to one, and only one, of the WBS Elements; · show Milestones or hold points; · show planned phasing of all the Work; · divide all Work into activities with appropriate logic ties to show overall approach to sequencing, including logical relationships between activities reflecting the actual intended sequence of work and logically tie all activities to avoid open ends; · avoid im...
Sample 1
AutoNDA by SimpleDocs

Related to Section Schedule General Requirements

  • General Requirements The Contractor hereby agrees:

  • Additional Requirements for All Policies All policies shall be endorsed to provide at least thirty (30) days' advance written notice to City of cancellation of policy for any reason, nonrenewal or reduction in coverage and specific notice mailed to City's address for notices pursuant to Article 15.

  • Additional Requirements As a condition precedent to the execution and Delivery, the registration of issuance, transfer, split-up, combination or surrender, of any ADS, the delivery of any distribution thereon, or the withdrawal of any Deposited Property, the Depositary or the Custodian may require (i) payment from the depositor of Shares or presenter of ADSs or of an ADR of a sum sufficient to reimburse it for any tax or other governmental charge and any stock transfer or registration fee with respect thereto (including any such tax or charge and fee with respect to Shares being deposited or withdrawn) and payment of any applicable fees and charges of the Depositary as provided in Section 5.9 and Exhibit B, (ii) the production of proof reasonably satisfactory to it as to the identity and genuineness of any signature or any other matter contemplated by Section 3.1, and (iii) compliance with (A) any laws or governmental regulations relating to the execution and Delivery of ADRs or ADSs or to the withdrawal of Deposited Securities and (B) such reasonable regulations as the Depositary and the Company may establish consistent with the provisions of the representative ADR, if applicable, the Deposit Agreement and applicable law.

  • Additional Request Requirements In addition to the requirements of Subparagraph 22A, the request for a WA must provide:

  • Personnel Requirements and Documentation Grantee will;

  • Schedule Requirements The Contractor shall submit an electronic and a paper copy of the initial Work Progress Schedule reflecting accurate and reliable representations of the planned progress of the Work, the Work to date if any, and of the Contractor’s actual plans for its completion. The Contractor shall organize and provide adequate detail so the Work Progress Schedule is capable of measuring and forecasting the effect of delaying events on completed and uncompleted activities.

  • General Requirement Any notice, election, demand, request, consent, approval, or other communication required or permitted to be given under this Contract shall be in writing signed by an officer or duly authorized representative of the party making same and shall be delivered personally or shall be sent by certified or statutory mail, postage prepaid, return receipt requested, shall be effective as of the date on which it is received or would have been received but for the refusal of the addressee to accept delivery, and shall be addressed as shown in the Contract. The persons and addresses to which notices should be given may be changed by notice given in accordance with this Article.

  • Operational Requirements 4 At-Sea Monitors are deployed, in accordance with coverage rates developed by 5 NMFS and as assigned through the Pre-Trip Notification System (PTNS), to 6 vessels. Due to availability of funding, changes in the fishery management, 7 such as emergency closures, court ordered closures, weather, and unforeseen 8 events must remain flexible. Additional funding for sea days may be added to 9 the contract within the scope and maximum allowable sea days. 10 The following items define the operational services to be provided by the 11 contractor under this contract.

  • Additional Requirements from Authorized Users An Authorized User may have distinct requirements that must be met by all individuals employed by or working for the Authorized User. The Contractor’s Staff Members will be expected to comply with these requirements as a condition of the placement.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

Time is Money Join Law Insider Premium to draft better contracts faster.