Schedule Relief Sample Clauses

Schedule Relief. If FM delays the commencement of construction or the occurrence of commercial operation, then the CC Longstop Date, Target COD, and COD Longstop Date will be extended for such reasonable period of delay directly resulting from such FM event. The occurrence of an event of FM which occurs after commercial operation of the facility will not extend the term. •
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Schedule Relief. Zarlink also shall be entitled to a day-for-day extension of any Milestone Date or any Scheduled Shipment Date to the extent that it is prevented from completing the applicable Milestone by such Milestone Date or, as the case may be, delivering Production Circuits by such Scheduled Shipment Date by any Force Majeure Event, provided that Zarlink complies with the conditions set forth in Section 14.2.
Sample 1
Schedule Relief. If a Relief Event occurs, then, if and to the extent the Relief Event, as a Supervening Event, relief is agreed or granted under Section 12 (Supervening Event Procedures), the Scheduled Substantial Completion Date and the Longstop Date shall be extended as and to the extent provided in Section 9.4 (Scheduled Substantial Completion Date and Longstop Date).
Sample 1
Schedule Relief. If a Compensation Event occurs, then the Substantial Completion Date and the Longstop Date shall be extended as and to the extent provided in Section 9.4 (Scheduled Substantial Completion Date and Longstop Date).
Sample 1

Related to Schedule Relief

  • Equitable Relief The parties hereto agree and declare that legal remedies may be inadequate to enforce the provisions of this Agreement and that equitable relief, including specific performance and injunctive relief, may be used to enforce the provisions of this Agreement.

  • Specific Performance and Injunctive Relief Notwithstanding the availability of legal remedies, Mortgagee will be entitled to obtain specific performance, mandatory or prohibitory injunctive relief, or other equitable relief requiring Mortgagor to cure or refrain from repeating any Default.

  • No Breach; Consents Except as set forth on SCHEDULE 4.7 hereto, the execution, delivery and performance of this Agreement by Seller and the consummation by Seller of the transactions contemplated hereby will not (i) result in any lien, pledge, mortgage, security interest, claim, lease, charge, option, easement, servitude or other encumbrance whatsoever (collectively, "Liens") upon any of the property of Seller (other than in favor of Buyer) or (ii) violate, conflict with or breach any of the terms and conditions of, result in a material modification of, accelerate or trigger the rights of any person under, or constitute (or with notice or lapse of time or both would constitute) a default under (a) any material instrument, contract or other agreement to which Seller is a party or by or to which it or any of its properties is bound or subject; (b) Seller's Certificate of Incorporation or By-laws (and all amendments thereto up through the date hereof); or (c) any Law applicable to Seller or any of its properties or operations. Except as set forth on SCHEDULE 4.7, no consent, approval or authorization of, or declaration or filing with, any governmental authority, stockholder of Seller or other person is required on the part of Seller in connection with the execution, delivery or performance of this Agreement or the consummation by it of the transactions contemplated hereby.

  • Arbitration and Equitable Relief IN CONSIDERATION OF EMPLOYEE’S EMPLOYMENT WITH THE COMPANY, ITS PROMISE TO ARBITRATE ALL EMPLOYMENT-RELATED DISPUTES, AND EMPLOYEE’S RECEIPT OF THE COMPENSATION, PAY RAISES, AND OTHER BENEFITS PAID TO EMPLOYEE BY THE COMPANY, AT PRESENT AND IN THE FUTURE, EMPLOYEE AGREES THAT ANY AND ALL CONTROVERSIES, CLAIMS, OR DISPUTES WITH ANYONE (INCLUDING THE COMPANY AND ANY EMPLOYEE, OFFICER, DIRECTOR, SHAREHOLDER, OR BENEFIT PLAN OF THE COMPANY, IN THEIR CAPACITY AS SUCH OR OTHERWISE), ARISING OUT OF, RELATING TO, OR RESULTING FROMEMPLOYEE’S EMPLOYMENT WITH THE COMPANY OR THE TERMINATION OF EMPLOYEE’S EMPLOYMENT WITH THE COMPANY, INCLUDING ANY BREACH OF THIS AGREEMENT, SHALL BE SUBJECT TO BINDING ARBITRATION UNDER THE ARBITRATION PROVISIONS SET FORTH IN THE WASHINGTON UNIFORM ARBITRATION ACT (THE “ACT”), AND PURSUANT TO WASHINGTON LAW, AND SHALL BE BROUGHT IN EMPLOYEE’S INDIVIDUAL CAPACITY, AND NOT AS A PLAINTIFF OR CLASS MEMBER IN ANY PURPORTED CLASS OR REPRESENTATIVE PROCEEDING. THE FEDERAL ARBITRATION ACT SHALL CONTINUE TO APPLY WITH FULL FORCE AND EFFECT NOTWITHSTANDING THE APPLICATION OF PROCEDURAL RULES SET FORTH IN THE ACT. DISPUTES THAT EMPLOYEE AGREES TO ARBITRATE, AND THEREBY AGREES TO WAIVE ANY RIGHT TO A TRIAL BY JURY, INCLUDE ANY STATUTORY CLAIMS UNDER LOCAL, STATE, OR FEDERAL LAW, INCLUDING, BUT NOT LIMITED TO, CLAIMS UNDER TITLE VII OF THE CIVIL RIGHTS ACT OF 1964, THE AMERICANS WITH DISABILITIES ACT OF 1990, THE AGE DISCRIMINATION IN EMPLOYMENT ACT OF 1967, THE OLDER WORKERS BENEFIT PROTECTION ACT, THE XXXXXXXX-XXXXX ACT, THE WORKER ADJUSTMENT AND RETRAINING NOTIFICATION ACT, THE CALIFORNIA FAIR EMPLOYMENT AND HOUSING ACT, THE FAMILY AND MEDICAL LEAVE ACT, ANY AND ALL CLAIMS UNDER THE REVISED CODE OF WASHINGTON OR ANY OTHER WASHINGTON STATE LABOR LAW, CLAIMS OF HARASSMENT, DISCRIMINATION, AND WRONGFUL TERMINATION, AND ANY STATUTORY OR COMMON LAW CLAIMS. NOTWITHSTANDING THE FOREGOING, EMPLOYEE UNDERSTANDS THAT NOTHING IN THIS AGREEMENT CONSTITUTES A WAIVER OF EMPLOYEE’S RIGHTS UNDER SECTION 7 OF THE NATIONAL LABOR RELATIONS ACT. EMPLOYEE FURTHER UNDERSTAND THAT THIS AGREEMENT TO ARBITRATE ALSO APPLIES TO ANY DISPUTES THAT THE COMPANY MAY HAVE WITH EMPLOYEE.

  • Injunctive Relief The Borrower recognizes that, in the event the Borrower fails to perform, observe or discharge any of its obligations or liabilities under this Agreement, any remedy of law may prove to be inadequate relief to the Lenders. Therefore, the Borrower agrees that the Lenders, at the Lenders’ option, shall be entitled to temporary and permanent injunctive relief in any such case without the necessity of proving actual damages.

  • Remedies and Injunctive Relief Executive acknowledges that a violation by Executive of any of the covenants contained in Sections 6, 7, 8, or 9 would cause irreparable damage to the Company in an amount that would be material but not readily ascertainable, and that any remedy at law (including the payment of damages) would be inadequate. Accordingly, Executive agrees that, notwithstanding any provision of this Agreement to the contrary, the Company shall be entitled (without the necessity of showing economic loss or other actual damage) to injunctive relief (including temporary restraining orders, preliminary injunctions, and permanent injunctions) in any court of competent jurisdiction for any actual or threatened breach of any of the covenants set forth in Sections 6, 7, 8, or 9 in addition to any other legal or equitable remedies it may have. The preceding sentence shall not be construed as a waiver of the rights that the Company may have for damages under this Agreement or otherwise, and all of the Company’s rights shall be unrestricted.

  • Specific Performance; Injunctive Relief The parties hereto acknowledge that Parent shall be irreparably harmed and that there shall be no adequate remedy at law for a violation of any of the covenants or agreements of the Stockholder set forth herein. Therefore, it is agreed that, in addition to any other remedies that may be available to Parent upon any such violation, Parent shall have the right to enforce such covenants and agreements by specific performance, injunctive relief or by any other means available to Parent at law or in equity.

Time is Money Join Law Insider Premium to draft better contracts faster.