RIGHT TO CANCEL FOR EXCESSIVE DELAY Sample Clauses

RIGHT TO CANCEL FOR EXCESSIVE DELAY. If the total accumulated time of all permissible and non-permissible delays, excluding delays due to (i) arbitration under Article XIII, (ii) the BUYER's defaults under Article XI, (iii) modifications and changes under Article V or (iv) delays or defects in the BUYER's supplies as stipulated in Article XII, aggregates two hundred and seventy (270) days or more, then, the BUYER may, at any time thereafter, cancel this CONTRACT by giving a written notice of cancellation to the BUILDER. Such cancellation shall be effective as of the date the notice thereof is received by the BUILDER. If the BUYER has not served the notice of cancellation as provided in the above or Article III.1. hereof, the BUILDER may, at any time after expiration of the accumulated time of the delay in delivery, either two hundred and seventy (270) days in case of the delay in this Paragraph or two hundred and ten (210) days in case of the delay in Article III.1, notify the BUYER of the future date upon which the BUILDER estimates the VESSEL will be ready for delivery and demand by email or facsimile that the BUYER make an election either to cancel this CONTRACT or to consent to the delivery of the VESSEL at such future date, in which case the BUYER shall, within seven (7) days after receipt of such demand, make and notify the BUILDER of such election. If the BUYER elects to consent to the delivery of the VESSEL at such future date (or other future date as the parties may agree):
Sample 1Sample 2Sample 3See All (48)
AutoNDA by SimpleDocs
RIGHT TO CANCEL FOR EXCESSIVE DELAY. If the total accumulated time for all delays on account of the causes specified in Paragraph 1 of this Article and non-permissible delays as described in Paragraph 1 of ARTICLE III aggregates to one hundred and twenty (120) days or more, excluding delays due to arbitration as provided for in ARTICLE XIII hereof, then in such event, the BUYER may in accordance with the provisions set out herein cancel this Contract by serving upon the SELLER telefaxed notice of cancellation in writing and the provisions of ARTICLE X of this Contract shall apply. The SELLER may, at any time, after the accumulated time of the aforementioned delays justifying cancellation by the BUYER as above provided for, demand in writing that the BUYER shall make an election, in which case the BUYER shall, within thirty (30) days after such demand is received by the BUYER either notify the SELLER of its intention to cancel, or consent to an extension of the time for delivery to an agreed future date. It being understood and agreed by the parties hereto that, if any further delay occurs on account of causes justifying cancellation as specified in this Contract, the BUYER shall have the right of immediate cancellation of the Contract upon the same terms as hereinabove provided.
Sample 1Sample 2Sample 3See All (9)
RIGHT TO CANCEL FOR EXCESSIVE DELAY. If the total accumulated time of all permissible and non-permissible delays, excluding delays due to (i) arbitration under Article XIII, (ii) the BUYER's defaults under Article XI, (iii)
Sample 1Sample 2Sample 3
RIGHT TO CANCEL FOR EXCESSIVE DELAY. If the total accumulated time of all delays on account of the causes specified in Paragraph 1 of the Article aggregate to Two Hundred and Ten (210) calendar days or more, or if the total accumulated time of all delays on account of the causes specified in Paragraph 1 of the Article and non-permissible delays as described in Paragraph 1 of Article III aggregate to Two Hundred and Forty (240) calendar days or more, in any circumstances, excluding delays due to arbitration as provided for in Article XIII hereof or due to default in performance by the BUYER, or due to delays in delivery of the BUYER's Supplied Items, and excluding delays due to causes which, under Article V, VI, XI and XII hereof, permit extension or postponement of the time for delivery of the VESSEL, then in such event, the BUYER at any time thereafter in accordance with the provisions set out herein rescind or cancel this Contract by serving upon the SELLER notice of cancel-lation or rescission by letter or email and the provisions of Article X of this Contract shall apply. The SELLER may, at any time, after the accumulated time of the aforementioned delays justifying cancellation by the BUYER as above provided for, demand in writing that the BUYER shall make an election, in which case the BUYER shall, within thirty (30) calendar days after such demand is received by the BUYER either notify the SELLER of its intention to cancel, or consent to an extension of the time for delivery to an agreed future date, it being understood and agreed by the parties hereto that, if any further delay occurs on account of causes justifying cancellation as specified in this Contract, the BUYER shall have the same right of cancellation upon the same terms as hereinabove provided.
Sample 1
RIGHT TO CANCEL FOR EXCESSIVE DELAY. If the total accumulated time of all delays claimed by the BUILDER on account of the causes specified in Paragraph 1 of this Article, excluding other delays of the nature which under the terms of this Contract permit postponement of the Delivery Date, amounts to Two Hundred and Ten (210) days or more, then, in such event, the BUYER may cancel this Contract in accordance with the provisions of Article X hereof. The BUILDER may, at any time after the accumulated time of the aforementioned delays justifying cancellation by the BUYER, demand in writing that the BUYER shall make an election, in which case the BUYER shall, within Fourteen (14) days after such demand is received by the BUYER, either notify the BUILDER of its intention to cancel this Contract, or consent to a postponement of the Delivery Date to an agreed specific future date; it being understood and agreed by the parties hereto that, if any further delay occurs on account of causes justifying cancellation as specified in this Article, the BUYER shall have the same right of cancellation upon the same terms as herein above provided. (End of Article)
Sample 1Sample 2
RIGHT TO CANCEL FOR EXCESSIVE DELAY. If either:
Sample 1

Related to RIGHT TO CANCEL FOR EXCESSIVE DELAY

  • Ability to Abandon CVR A Holder may at any time, at such Holder’s option, abandon all of such Holder’s remaining rights in a CVR by transferring such CVR to Parent without consideration therefor. Nothing in this Agreement is intended to prohibit Parent from offering to acquire CVRs for consideration in its sole discretion.

  • Waiver of Right to Partition The Partners, by execution of this Agreement, waive their respective rights to partition of the Partnership Property.

  • Right to Cancel You have a right to cancel this Agreement for a period of fourteen (14) days commencing on the date on which this Agreement is concluded or the date on which you receive this Agreement (whichever is later) (the “Cancellation Period”). Should you wish to cancel this Agreement within the Cancellation Period, you should send notice in writing or electronically to the addresses found in contact us section of our website. Cancelling this Agreement within the Cancellation Period will not cancel any Transaction entered into by you during the Cancellation Period. If you fail to cancel this Agreement within the Cancellation Period, you will be bound by its terms but you may terminate this Agreement in accordance with Clause 17 (Termination Without Default).

  • Company Not to Diminish Benefits of Rights The Company covenants and agrees that after the earlier of the Shares Acquisition Date or Distribution Date it will not, except as permitted by Section 23, Section 26 or Section 27, take (or permit any Subsidiary to take) any action if at the time such action is taken it is reasonably foreseeable that such action will substantially diminish or otherwise eliminate the benefits intended to be afforded by the Rights.

  • Right to Work For purposes of federal immigration law, you will be required to provide to the Company documentary evidence of your identity and eligibility for employment in the United States. Such documentation must be provided to us within three (3) business days of your Start Date, or our employment relationship with you may be terminated.

  • Termination of the Right to Use Upon termination of this Addendum for any reason, any right to use the System and access to the Data Access Services shall terminate and the Fund shall immediately cease use of the System and the Data Access Services. Immediately upon termination of this Addendum for any reason, the Fund shall return to State Street all copies of documentation and other Proprietary Information in its possession; provided, however, that in the event that either party terminates this Addendum or the Custodian Agreement for any reason other than the Fund’s breach, State Street shall provide the Data Access Services for a period of time and at a price to be agreed upon in writing by the parties.

  • RIGHT TO SHOW PREMISES Lessor may show the Premises to prospective purchasers and mortgagees; and during the twelve (12) months prior to termination of this Lease, to prospective tenants, during Building Hours on reasonable notice to Lessee.

  • Lessor's Right to Perform for Lessee If Lessee fails to make any payment of Rent required to be made by it hereunder or fails to perform or comply with any of its agreements contained herein, then (but in each case, except in the case of failure to pay Rent or in the case of failure to maintain insurance as required hereunder, no earlier than the fifteenth day after the occurrence of such failure, whether or not it shall yet constitute an Event of Default hereunder) Lessor may itself make such payment or perform or comply with such agreement but shall not be obligated hereunder to do so, and the amount of such payment and the amount of the reasonable expenses of Lessor incurred in connection with such payment or the performance of or compliance with such agreement, as the case may be, together with interest thereon at the Past Due Rate, shall be deemed Supplemental Rent, payable by Lessee upon demand.

Time is Money Join Law Insider Premium to draft better contracts faster.