RFQ Schedule Sample Clauses

RFQ Schedule. The proposed schedule for the selection of a firm or individual for this project is set forth below: Issue Date: January 18, 2022. Closing Date: February 15, 2022. Shortlisting: February 24, 2022 Sealed bids, proposals, or replies received by the City pursuant to a competitive solicitation are exempt from s.119.07(1) and s. 24(a), Art. I of the State Constitution until such time as the agency provides notice of an intended decision or until 30 days after opening the bids, proposals, or final replies, whichever is earlier.
Sample 1
AutoNDA by SimpleDocs
RFQ Schedule. The table below shows the intended schedule for this RFQ. Catawba County will make every effort to adhere to this schedule. Event Responsibility Date and Time Issue RFQ County October 18, 2019 Submitted Written Questions Firms October 30, 2019 at 5:00 PM Provide Responses to Questions County November 1, 2019 at 5:00 PM Submit Proposals Firms November 15, 2019 at 5:00 PM Contract Award County TBA Anticipated Contract Effective Date County December 17, 2019 The qualifications statement shall be submitted no later than 5:00 p.m. November 15, 2019. No submittals will be accepted after the deadline. Once the submittals have been reviewed, the County reserves the right to shortlist Firm(s) and request that the Firm(s) conduct a presentation and be interviewed by the selection committee. RFQ QUESTIONS Written questions shall be emailed to xxxxxxxxxx@xxxxxxxxxxxxxxx.xxx by the date and time specified above. Firms should enter “RFQ # 20-1001 – Questions” as the subject for the email. Questions received prior to the submission deadline date, the County’s response, and any additional terms deemed necessary by the County will be posted in the form of an addendum to the Catawba County website, xxxxx://xxx.xxxxxxxxxxxxxxx.xxx/county-services/purchasing/bid-notices/ and shall become an Addendum to this RFQ. No information, instruction or advice provided orally or informally by any County personnel, whether made in response to a question or otherwise in connection with this RFQ, shall be considered authoritative or binding. Firms shall rely only on written material contained in an Addendum to this RFQ. SUBMISSION OF QUALIFICATIONS Respondents may submit qualifications for any one, or all the various tasks listed in the Scope of Services. Respondents are required to clearly identify in their responses which tasks within the Scope of Services they are submitting qualifications for. The qualifications statement must be submitted with one (1) original, one (1) copy and one
Sample 1

Related to RFQ Schedule

  • RDO Schedule a) The Schedule of RDO’s to be observed each year will generally be as provided under the VBIA.

  • Shift Schedule The words "shift schedule" when used in this Agreement shall mean a timetable of the shifts and off days assigned to a position or group of positions which commences at the beginning of a pay period and includes one complete rotation of said shifts.

  • Fourth Schedule All petroleum as defined in the Xxxxxxxxx Xxx 0000 on or below the surface of the land the subject of this lease is reserved to the Crown in right of the State of Western Australia with the right of the Crown in right of the State of Western Australia and any person lawfully claiming thereunder or otherwise authorised to do so to have access to the land the subject of this lease for the purpose of searching for and for the operations of obtaining petroleum (as so defined) in any part of the land. FIFTH SCHEDULE (Date of commencement of the lease). SIXTH SCHEDULE (Any further conditions or stipulations).

  • Schedule The Work shall be performed as expeditiously as possible in conformity with the schedule requirements contained herein and in the Statement of Work. The draft and final versions of all deliverables shall be submitted by the dates specified in the Exhibit A Schedule and Project Period noted in Item No. 7 of this Agreement. It is understood and agreed that the delivery of the draft and final versions of such deliverables by the Contractor shall occur in a timely manner and in accordance with the requirements of the Exhibit A Schedule.

  • PROGRESS SCHEDULE The Contractor, within ten (10) working days of receiving notice of the award of the contract, shall prepare and submit for the State's and Architect's information an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work.

  • Time Schedule 4.1. A project schedule is included in Appendix A.

  • Master Schedule At the start of the schematic design phase, the Construction Administrator will be given a copy of the updated DAS initial schedule as described in the pre-design phase. The Construction Administrator will then create its master schedule based on the DAS’ initial schedule. Utilizing CPM-based software, the Construction Administrator will assign a duration and relationship to each task, add or delete tasks, identify the logic of interrelationships and milestones, and perform schedule management activities to identify the project's critical path and timeline. The master schedule shall include all tasks from the pre-design phase through design, construction, and project closeout. Items to be identified during subsequent refinements include milestones for departmental occupancy, shop drawing and Construction Administrator reviews, special support services, mobilization and demobilization, long lead item purchases, and float times.

  • Wage Schedule ‌ The pay rate (including increments and stated extras) as agreed to and hereinafter in this Schedule provided, shall be in effect during the term of the Agreement, from April 1, 2019 to March 31, 2022.

  • Preliminary Schedule A preliminary schedule of construction indicating the starting and completion dates of the various stages of the Work, including any information and following any form as may be specified in the Specifications. Once approved by District, this shall become the Construction Schedule. This schedule shall include and identify all tasks that are on the Project’s critical path with a specific determination of the start and completion of each critical path task as well as all Contract milestones and each milestone’s completion date(s) as may be required by the District.

  • Daily Schedule 1. Double Bus Runs - Teachers shall be required to be on duty a total of seventy-five (75) minutes in grades K-6 and sixty (60) minutes in grades 7-12 before and after the published regular pupil's school day.

Time is Money Join Law Insider Premium to draft better contracts faster.