RESOLUTION OF AGREEMENT CLAIMS Sample Clauses

RESOLUTION OF AGREEMENT CLAIMS. A. For purposes of this Section, the term "Claim" has the meaning as set forth in Public Contract Code section 20104(b)(2), as that section may be amended from time to time. Section 20104(b) (2) currently defines "claim" to mean a separate demand by the Contractor for (a) time extension, (b) payment of money or damages arising from work done by or on behalf of the Contractor pursuant to the Construction Services Agreement and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to, or (c) an amount the payment of which is disputed by the District.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
RESOLUTION OF AGREEMENT CLAIMS. (a) Architect shall within a reasonable time, make decisions on all claims of District or Contractor and on all other matters relating to the execution and progress of the Project. The decisions of Architect shall not be binding, but shall be advisory only.
Sample 1Sample 2Sample 3See All (7)
RESOLUTION OF AGREEMENT CLAIMS. 20.1 D ecision of Architect. “Disputes” or “
Sample 1
RESOLUTION OF AGREEMENT CLAIMS. 20.1 Decision of Architect. “
Sample 1
RESOLUTION OF AGREEMENT CLAIMS. All public works claims, as defined below, that arise out of or relate to this Construction Services Agreement, or a breach thereof, shall include a statement as to whether Contractor elects to proceed pursuant to Claim Resolution Process 1 or Claim Resolution Process 2, as identified below. Contractor must follow the requirements of its selected Claim Resolution Process throughout its entire claim. Claim Resolution Process 1 Claim Resolution Process 1 is set forth in Public Contract Code Section 9204, as that section may be amended from time to time, and applies to any claim between Contractor and District, without regard to the claim’s dollar amount. For purposes of Claim Resolution Process 1, the term “claim” has the meaning set forth in Public Contract Code Section 9204(c)(1), as that section may be amended from time to time. Section 9204(c)(1) currently defines “claim” to mean a separate demand by Contractor sent by registered mail or certified mail with return receipt requested for one or more of the following: (a) A time extension, including, without limitation, for relief from damages or penalties for delay assessed by District under this Construction Services Agreement; (b) Payment by District of money or damages arising from work done by, or on behalf of, Contractor pursuant to this Construction Services Agreement and payment for which is not otherwise expressly provided or to which the claimant is not otherwise entitled; and/or (c) Payment of an amount that is disputed by District.
Sample 1
RESOLUTION OF AGREEMENT CLAIMS 
Sample 1Sample 2Sample 3See All (10)

Related to RESOLUTION OF AGREEMENT CLAIMS

  • Review of Agreement Each party acknowledges that it has had time to review this agreement and, as desired, consult with counsel. In the interpretation of this agreement, no adverse presumption shall be made against any party on the basis that it has prepared, or participated in the preparation of, this agreement.

  • Indemnification for Certain Claims The Party providing services hereunder, its affiliates and its parent company, shall be indemnified, defended and held harmless by the Party receiving services hereunder against any claim, loss or damage arising from the receiving company’s use of the services provided under this Agreement pertaining to (1) claims for libel, slander or invasion of privacy arising from the content of the receiving company’s own communications, or (2) any claim, loss or damage claimed by the End User of the Party receiving services arising from such company’s use or reliance on the providing company’s services, actions, duties, or obligations arising out of this Agreement.

  • Execution of Agreement The HSP represents and warrants that:

  • CERTIFICATION OF AGREEMENT In accordance with Division 4 of Part VIB of the Workplace Relations Act 1996, the Commission hereby certifies the attached written agreement in this matter. This agreement shall come into force from the date of certification, being 6 May 2003, shall operate in accordance with its terms and shall remain in force until 31 October 2005. Printed by authority of the Commonwealth Government Printer <Price code 40> GLADWYN PLUMBING PTY LTD & C E P U ENTERPRISE AGREEMENT 2002-2005 PLUMBING and MECHANICAL SERVICES ENTERPRISE AGREEMENT 2002 - 2005 Subject Matter Clause number Page number Annual Leave 27 17 Application of Site Agreements 20 13 Apprentices 16 10 Certification & Date of Operation 6 3 Commitments 3 2 Compensation of Tools of Trade 35 22 Consultative Mechanisms 8 3 Co-Invest 36 23 Dispute Settlement Procedure 12 5 Hours of Work 22 13 Industry Compliance Certificate 21 14 Industry Training 15 10 Inclement Weather 14 6 Insurances 29 18 Negotiation of a Subsequent Agreement 19 12 No extra claims 18 13 Occupational Health & Safety 13 5 Objectives 2 2 Parties & Persons Bound 4 2 Payment of Wages 26 15 Picnic Day 34 22 Plumbing Industry Calendar 32 22 Public Holidays 33 22 Protective Clothing 31 20 Relationship with Parent Award & VBIA 7 3 Right of Entry 11 4 Rostered Days Off 23 14 Scope & Application 5 3 Security of Employment 37 23 Shift Work 24 15 Shop Stewards 9 4 Superannuation 28 18 Termination of Employment & Redundancy 30 20 Title 1 2 Compensation for Tools of Trade 35 22 Union Representation 10 4 Wages & Allowances 25 17 Appendix A Wage Rates & Allowances Availability Appendix B Victorian Building Industry Site Agreement Appendix C Security of Employment Arrangements

  • Conclusion of Agreement 3.1. The Assignee confirms that it has familiarized itself with the Terms and Conditions of the Portal User and the terms and conditions of the Agreement, understands the rights and obligations arising therefrom and confirms that the terms and conditions thereof conform to the will of the Assignee.

  • COMPLETION OF AGREEMENT The District and the Union agree that this contract is complete. There shall be no additions to or deletions from the content of any Articles and there shall be no Articles added except by mutual agreement by the Board and the Union. In addition, there shall be no further negotiations on any matter that is within or comes within the scope of representation for the duration of the contract except by mutual agreement.

  • SCOPE OF AGREEMENT Nothing in this Agreement shall be deemed to entitle Executive to continued employment with the Company or its Subsidiaries, and if Executive’s employment with the Company shall terminate prior to a Change in Control, Executive shall have no further rights under this Agreement (except as otherwise provided hereunder); provided, however, that any termination of Executive’s employment during the Termination Period shall be subject to all of the provisions of this Agreement.

  • Application of Agreement 4.1 This Agreement applies to:

  • PROCUREMENT OF AGREEMENT CONSULTANT represents and warrants that no person or selling agent has been employed or retained by CONSULTANT to solicit or secure this Agreement upon an agreement or upon an understanding for a commission, percentage, a brokerage fee, contingent fee or any other compensation. CONSULTANT further represents and warrants that no payment, gift or thing of value has been made, given or promised to obtain this or any other agreement between the parties. CONSULTANT makes such representations and warranties to induce the COUNTY to enter into this Agreement and the COUNTY relies upon such representations and warranties in the execution hereof. For a breach or violation of such representations or warranties, the COUNTY shall have the right to annul this Agreement without liability, entitling the COUNTY to recover all monies paid hereunder and CONSULTANT shall not make claim for or be entitled to recover, any sum or sums otherwise due under this Agreement. This remedy, if effected, shall not constitute the sole remedy afforded the COUNTY for such falsity or breach, not shall it constitute a waiver of the COUNTY’s right to claim damages or otherwise refuse payment or to take any other action provided for by law or pursuant to this Agreement.

  • Implementation of Agreement Each Party must promptly execute all documents and do all such acts and things as is necessary or desirable to implement and give full effect to the provisions of this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.