Request for Extension of Time Sample Clauses

Request for Extension of Time. If the performance of any act required of Consultant is directly prevented or delayed by reason of strikes, lockouts, labor disputes, unusual governmental delays, acts of God, fire, floods, epidemics, freight embargoes, or other causes beyond the reasonable control of the Consultant, as determined by the City, Consultant shall be excused from performing that act for the period of time equal to the period of time of the prevention or delay. In the event Consultant claims the existence of such a delay, the Consultant shall notify the City's Contract Administrator, or designee, in writing of that fact within ten calendar days after the beginning of any such claimed delay. Extensions of time will not be granted for delays to minor portions of work unless it can be shown that such delays did or will delay the progress of the work.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Request for Extension of Time. In the event the Subcontractor's performance of this Subcontract is delayed or interfered with by acts of the Owner, Contractor or other subcontractors, it may request an extension of time for the performance of same, as hereinafter provided, but shall not be entitled to any increase in the Subcontract price or to damages or additional compensation as a consequence of such delays. If a progress schedule is furnished by Contractor to Subcontractor, it shall be solely for Contractor's benefit; however, Subcontractor must be ready to perform at the times indicated in the progress schedule. The Contractor makes no representation that it will be ready for the Subcontractor at the times indicated in said schedule regardless of whether delays may be occasioned by circumstances within the control of the Contractor. As required by the Contractor, the Subcontractor shall submit to the Contractor progress schedules for the work subcontracted, or at the Contractor's election, cooperate in the preparation of a progress schedule. DRAFT No allowance of an extension of time, for any cause whatever, shall be claimed by the Subcontractor or be made to it, unless the Subcontractor shall have made written request upon the Contractor for such extension within forty‐eight hours after the cause for such extension occurred and unless the Contractor and Subcontractor have agreed in writing upon the allowance of additional time to be made. If such extension of time is requested as aforesaid and Contractor and Subcontractor cannot agree thereupon, the Owner's Representative shall determine by certificate in writing what, if any, extension of time shall be allowed. No allowance of an extension of time shall in any event be made to the Subcontractor for delay by the Subcontractor in preparing drawings or in securing approval of the Owner's Representative thereto when such drawings are not properly prepared or when the Subcontractor by the exercise of reasonable diligence and judgment could have anticipated and avoided the delay. If Owner, with or without cause, shall terminate the General Contract or shall stop or suspend work under the General Contract, or if Owner shall fail to pay when due any sum payable under the General Contract, Contractor may order Subcontractor to stop or suspend work hereunder, and Contractor shall be liable to Subcontractor for any such stoppage or suspension only if and to the extent that Owner shall be liable to Contractor therefor. Contractor will pay to...
Sample 1
Request for Extension of Time. In support of its request for an extension of time to complete this project, Norfolk Southern Railway Company (“Norfolk Southern”) states:
Sample 1
Request for Extension of Time. The Contractor agrees to supply, as soon as such data are available, any reasonable proof that is required by SFMTA to decide on any request for an extension of time. SFMTA shall examine the request and any documents supplied by the Contractor and shall determine if the Contractor is entitled to an extension of time and the duration of such extension. SFMTA shall notify the Contractor of its decision in writing. The granting of an extension of time because of Unavoidable Delays shall in no way operate as a waiver on the part of the City of the right to collect liquidated damages for other delays or of any other rights to which the City is entitled.
Sample 1
Request for Extension of Time. 1. Before the Project Manager acts on the Contractor's request for time extension, the Contractor must submit a written application to the Project Manager within ten (10) days after commencement of the condition that allegedly has caused the delay, with the following information:
Sample 1
Request for Extension of Time. 18.1. If the Contractor is delayed at any time in the commencement or progress of the Detailed Scope of Work by an act or neglect of the NJPA Member or Project Manager, or of an employee of either, or of a separate contractor employed by the NJPA Member, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Contractor’s control, or by other causes which the Project Manager determines may justify delay, then the Work Order Completion Time shall be extended for such reasonable time as the Project Manager may determine.
Sample 1

Related to Request for Extension of Time

  • Request for Extension Upon request, the Department may extend the time allowed for both a response to the Letter of Concern and a Corrective Action Plan depending upon the nature of the deficiency. The Provider shall request an extension of time in writing from the Department’s designated representative. The written request shall contain a justification and proposed extension period.

  • Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.

  • No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:

  • Extension of Agreement Prior to the original expiration date of this Agreement, the Parties mutually agree to extend this Agreement to the February 15 extension date identified in Paragraph VIII(A). The Parties acknowledge that no further extensions of this Agreement are authorized. Xxxxxxxxx has hereunto signed on this Day of , 20 . Landowner(s): The Secretary of the Department of Agriculture, acting and through his or her authorized representative has executed this Contract on behalf of the United States of America on this Day of , 20 . THE UNITED STATES OF AMERICA BY: NONDISCRIMINATION STATEMENT The U.S. Department of Agriculture (USDA) prohibits discrimination in all its programs and activities on the basis of race, color, national origin, age, disability, and where applicable, sex, marital status, familial status, parental status, religion, sexual orientation, genetic information, political beliefs, reprisal, or because all or a part of an individual’s income is derived from any public assistance program. (Not all prohibited bases apply to all programs.) Persons with disabilities who require alternative means for communication of program information (Braille, large print, audiotape, etc.) should contact USDA’s TARGET Center at 0 (000) 000-0000 (voice and TDD). To file a complaint of discrimination, write to USDA, Director, Office of Civil Rights, 0000 Xxxxxxxxxxxx Xxxxxx, XX., Xxxxxxxxxx, XX 00000-0000 or call (000) 000-0000 (voice) or (000) 000-0000 (TDD). USDA is an equal opportunity provider and employer. PRIVACY ACT STATEMENT

  • Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.

  • Request for Exemption Grantee may request written approval from Grantor for an exemption from Paragraph 21.2. Grantee acknowledges that Grantor is under no obligation to provide such exemption and that Grantor may, if an exemption is granted, grant such exemption subject to such additional terms and conditions as Grantor may require.

  • Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.

  • Contract Negotiation Meetings 14.09 When operational requirements permit, the Employer will grant leave without pay to an employee for the purpose of attending contract negotiation meetings on behalf of the Alliance. Preparatory Contract Negotiation Meetings

  • EXTENSION OF THE SEASON Concessionaire may request to extend the Period of Operation either prior to the Saturday before Memorial Day and/or after Labor Day. All requests shall be submitted to both the Office of Leases & Concessions and the Area Superintendent, in writing, at the addresses set forth in Subparagraph 5(B) and Paragraph 49, respectively, fifteen (15) calendar days in advance of the proposed implementation. Approval of this request shall be within Department’s sole discretion. Concessionaire shall be deemed to not have permission to extend the Period of Operation without written approval from the Office of Leases & Concessions and the Area Superintendent. Additional compensation to Department for the extended period shall be calculated by Department on a monthly basis or prorated by day and must be submitted by check made payable to “Treasurer – State of New Jersey” and sent to the address set forth in Subparagraph 5(B). The additional compensation must be received by Department in advance of operation for the extended period.

Time is Money Join Law Insider Premium to draft better contracts faster.