Provision of Interconnection Financial Security The Interconnection Customer is obligated to provide all necessary Interconnection Financial Security required under Section 11 of the GIDAP in a manner acceptable under Section 11 of the GIDAP. Failure by the Interconnection Customer to timely satisfy the GIDAP’s requirements for the provision of Interconnection Financial Security shall be deemed a breach of this Agreement and a condition of Default of this Agreement.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Agreement Amount The Grantee acknowledges and agrees that, notwithstanding any other provision of this Agreement, the maximum amount payable by the City under this Agreement for the initial ## month term shall not exceed the amount approved by City Council, which is $ (dollar amount), and $ (dollar amount) per ## month extension option, for a total Agreement amount of $ . Continuation of the Agreement beyond the initial ## months is specifically contingent upon the availability and allocation of funding, and authorization by City Council.
Interconnection Customer Payments Not Taxable The Parties intend that all payments or property transfers made by the Interconnection Customer to the Participating TO for the installation of the Participating TO's Interconnection Facilities and the Network Upgrades shall be non-taxable, either as contributions to capital, or as a refundable advance, in accordance with the Internal Revenue Code and any applicable state income tax laws and shall not be taxable as contributions in aid of construction or otherwise under the Internal Revenue Code and any applicable state income tax laws.
Payment of Settlement Amount (1) Within thirty (30) days of the Date of Execution, the Settling Defendants shall pay the Settlement Amount to Siskinds LLP, for deposit into the Trust Account.
Initial Payment - Transportation Charge Minimum Component Payments by the Agency under the minimum operation, maintenance, power, and replacement component of the Transportation Charge shall commence for each aqueduct reach in the year following the year in which construction of that reach is completed.
Payment Amounts The aggregate Payments to be made in any fiscal year shall not exceed an amount that is equal to the corresponding Appropriated Amount. (For example, for the Payments due on December 1, 2022 and on June 1, 2023, the aggregate maximum amount of such Payments would be determined by the Appropriated Amount determined for certification by December 1, 2021.) Furthermore, the amount of each such Payment shall not exceed the amount of Incremental Property Tax Revenues (excluding allocations of “back-fill” or “make-up” (payments from the State of Iowa for property tax credits or roll-back) actually received by the City from the Dubuque County Treasurer attributable to the taxable incremental valuation of the Property in the six (6) months immediately preceding the extant Payment due date.
Reimbursement Amount Except for the metropolitan areas listed below, the maximum reimbursement for meals including tax and gratuity, shall be: Breakfast $ 9.00 Lunch $11.00 Dinner $16.00 For the following metropolitan areas the maximum reimbursement shall be: Breakfast $11.00 Lunch $13.00 Dinner $20.00 The metropolitan areas are: Atlanta Boston Cleveland Denver Hartford Kansas City Miami New York City Portland, OR San Francisco St. Louis Baltimore Chicago Dallas/Fort Worth Detroit Houston Los Angeles New Orleans Philadelphia San Diego Seattle Washington D.C. See Appendix L for details related to the boundaries of the above-mentioned metropolitan areas. The metropolitan areas also include any location outside the forty-eight (48) contiguous United States. Employees who meet the eligibility requirements for two (2) or more consecutive meals shall be reimbursed for the actual costs of the meals up to the combined maximum reimbursement amount for the eligible meals.
Interconnection Facility Options The Intercarrier Compensation provisions of this Agreement shall apply to the exchange of Exchange Service (EAS/Local) traffic between CLEC's network and Qwest's network. Where either Party acts as an IntraLATA Toll provider, each Party shall xxxx the other the appropriate charges pursuant to its respective tariff or price lists. Where either Party interconnects and delivers traffic to the other from third parties, each Party shall xxxx such third parties the appropriate charges pursuant to its respective tariffs, price lists or contractual offerings for such third party terminations. Absent a separately negotiated agreement to the contrary, the Parties will directly exchange traffic between their respective networks without the use of third party transit providers.
Maximum Contract Amount 4.4.1. Notwithstanding any other provision of this Agreement, the City’s maximum payment obligation will not exceed ($_) (the “Maximum Contract Amount”). The City is not obligated to execute an agreement or any amendments for any further services, including any services performed by the Contractor beyond that specifically described in Exhibit A. Any services performed beyond those in Exhibit A or performed outside the Term are performed at the Contractor’s risk and without authorization under this Agreement.
