Extended Warranty If the Quote includes an extended warranty, the extended warranty coverage period warranty will be for a 5-year term, which includes the hardware manufacturer’s warranty plus the 4-year extended term.
Cost Responsibility for Interconnection Facilities and Distribution Upgrades 4.1 Interconnection Facilities 4.2 Distribution Upgrades
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Contractor Commitments, Warranties and Representations Any written commitment received from the Contractor concerning this Agreement shall be binding upon the Contractor, unless otherwise specifically provided herein with reference to this paragraph. Failure of the Contractor to fulfill such a commitment shall render the Contractor liable for damages to the County. A commitment includes, but is not limited to any representation made prior to execution of this Agreement, whether or not incorporated elsewhere herein by reference, as to performance of services or equipment, prices or options for future acquisition to remain in effect for a fixed period, or warranties.
Replacement Parts Warranty If during the regular or extended warranty period’s faults develop, the Contractor shall promptly repair or, upon demand, replace the defective unit or component part affected. All costs for labor and material and transportation incurred to repair or replace defective Product during the warranty period shall be borne solely by the Contractor, and the State or Authorized User shall in no event be liable or responsible therefor. Any part of component replaced by the Contractor under the Contract warranty shall be replaced at no cost to the Authorized User and guaranteed for the greater of: a) the warranty period under paragraph (d) above; or b) if a separate warranty for that part or component is generally offered by the manufacturer, the standard commercial warranty period offered by the manufacturer for the individual part or component.
Payment of Premiums; Substitution of Policy; Loss Reserve; Protection of Lender If Lender required Mortgage Insurance as a condition of making the Loan, Borrower will pay the premiums required to maintain the Mortgage Insurance in effect. If Borrower was required to make separately designated payments toward the premiums for Mortgage Insurance, and (i) the Mortgage Insurance coverage required by Lender ceases for any reason to be available from the mortgage insurer that previously provided such insurance, or (ii) Lender determines in its sole discretion that such mortgage insurer is no longer eligible to provide the Mortgage Insurance coverage required by Lender, Borrower will pay the premiums required to obtain coverage substantially equivalent to the Mortgage Insurance previously in effect, at a cost substantially equivalent to the cost to Borrower of the Mortgage Insurance previously in effect, from an alternate mortgage insurer selected by Xxxxxx. If substantially equivalent Mortgage Insurance coverage is not available, Borrower will continue to pay to Lender the amount of the separately designated payments that were due when the insurance coverage ceased to be in effect. Lender will accept, use, and retain these payments as a non-refundable loss reserve in lieu of Mortgage Insurance. Such loss reserve will be non-refundable, even when the Loan is paid in full, and Lender will not be required to pay Borrower any interest or earnings on such loss reserve. Lender will no longer require loss reserve payments if Mortgage Insurance coverage (in the amount and for the period that Lender requires) provided by an insurer selected by Lender again becomes available, is obtained, and Lender requires separately designated payments toward the premiums for Mortgage Insurance. If Lender required Mortgage Insurance as a condition of making the Loan and Borrower was required to make separately designated payments toward the premiums for Mortgage Insurance, Borrower will pay the premiums required to maintain Mortgage Insurance in effect, or to provide a non-refundable loss reserve, until Lender’s requirement for Mortgage Insurance ends in accordance with any written agreement between Borrower and Lender providing for such termination or until termination is required by Applicable Law. Nothing in this Section 11 affects Borrower’s obligation to pay interest at the Note rate.
How Long Does Warranty Coverage Last? The warranty lasts for a period up to 5 YEARS after the instal- lation date. This warranty period does not continue after the unit is re- moved from the location where it was originally installed. The replacement of a part under this warranty does not extend the warranty period. In other words, Daikin warrants a replacement part only for the period remaining in the war- ranty term that commenced on the installation date. What Xxxx Xxxxxx Do To Correct Problems? Daikin will furnish a replacement part, without charge for the part only, to replace any part that is found to be defective due to workmanship or materials under normal use and mainte- xxxxx. Furnishing of the replacement part is Daikin’s only responsibility under this warranty. THE APPLICABLE REMEDIES DESCRIBED IN THIS SECTION ARE DAIKIN’S ONLY RESPONSIBILITIES, AND THE OWNER’S ONLY REMEDIES, FOR ANY BREACH OF THIS WARRANTY OR ANY IMPLIED WARRANTY. Part No. PWDCLAHTWZQE COMMERCIAL WARRANTY Models: ACNF, ARUF, ASPT, AWST, AWUF, AWUT, AMST, CAPF, CAPFA, CAPT, CAUF, CAUFA, CAPEA, CAPE, CHPF, CHPE, CSCF, CAPTA, CHPTA, CHPT, MBVC What Won’t Daikin Do To Correct Problems? Daikin will not pay for: • Labor, freight, or any other cost associated with the service, repair, or operation of the unit. • Electricity or fuel costs, or increases in electricity or fuel costs, for any reason, including additional or unusual use of supplemental electric heat. • Lodging or transportation charges. • Refrigerant. WHETHER ANY CLAIM IS BASED ON NEGLIGENCE OR OTH- ER TORT, BREACH OF WARRANTY OR OTHER BREACH OF CONTRACT, OR ANY OTHER THEORY, NEITHER DAIKIN NOR ANY OF ITS AFFILIATES SHALL IN ANY EVENT BE LIABLE FOR INCIDENTAL OR CONSEQUENTIAL DAMAGES, INCLUDING BUT NOT LIMITED TO LOST PROFITS, LOSS OF USE OF A UNIT, EXTRA UTILITY EXPENSES, OR DAMAGES TO PROPERTY.
Treatment of Unallowable Costs Previously Submitted for Payment Defendants further agree that within 90 days of the Effective Date of this Agreement they shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this Paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Defendants or any of their subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Defendants agree that the United States, at a minimum, shall be entitled to recoup from Defendants any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Defendants or any of their subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this Paragraph) on Defendants or any of their subsidiaries or affiliates’ cost reports, cost statements, or information reports.
CREDIT UNION LIABILITY FOR FAILURE TO MAKE TRANSFERS If we do not complete a transfer to or from your account on time or in the correct amount according to our agreement with you, we may be liable for your losses or damages. However, we will not be liable for direct or consequential damages in the following events: - If, through no fault of ours, there is not enough money in your accounts to complete the transaction, if any funds in your accounts necessary to complete the transaction are held as uncollected funds pursuant to our Funds Availability Policy Disclosure, or if the transaction involves a loan request exceeding your credit limit. - If you used your card or access code in an incorrect manner. - If the ATM where you are making the transfer does not have enough cash. - If the ATM was not working properly and you knew about the problem when you started the transaction. - If circumstances beyond our control (such as fire, flood, or power failure) prevent the transaction. - If the money in your account is subject to legal process or other claim. - If funds in your account are pledged as collateral or frozen because of a delinquent loan. - If the error was caused by a system of any participating ATM network. - If the electronic transfer is not completed as a result of your willful or negligent use of your card, access code, or any EFT facility for making such transfers. - If the telephone or computer equipment you use to conduct audio response, online/PC, or mobile banking transactions is not working properly and you know or should have known about the breakdown when you started the transaction. - If you have xxxx payment services, we can only confirm the amount, the participating merchant, and date of the xxxx payment transfer made by the Credit Union. For any other error or question you have involving the billing statement of the participating merchant, you must contact the merchant directly. We are not responsible for investigating such errors. - Any other exceptions as established by the Credit Union.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Secondary / Post-Secondary Program Alignment Welding HIGH SCHOOL COURSE SEQUENCE 9th Grade 10th Grade 11th Grade 12th Grade English 9 Algebra I World History/Geography Biology World Language Phys Ed/Health English 10 Geometry U.S. History/Geography Physics or Chemistry World Language Visual/Performing/Applied Arts English 11 Algebra II Civics/Economics Welding English 12 Math Credit Science Credit Welding WASHTENAW COMMUNITY COLLEGE Welding Associate in Applied Science Semester 1 Math Elective(s)* 3 WAF 105 Introduction to Welding Processes 2 WAF 111 Oxy-fuel Welding 4 WAF 112 Shielded Metal Arc Welding 4 Semester Total 13 Semester 2 Speech Elective(s) 3 WAF 106 Blueprint Reading for Welders 3 WAF 123 Advanced Oxy-fuel Welding 4 WAF 124 Advanced Shielded Metal Arc Welding 4 Semester Total 14 Semester 3 Arts/Human. Elective(s) 3 Computer Lit. Elective(s) 3 WAF 215 Advanced Gas Tungsten Arc Welding 4 WAF 288 Gas Metal Arc Welding 4 Semester Total 14 Semester 4 WAF 200 Layout Theory Welding 3 WAF 210 Welding Metallurgy 3 Soc. Sci. Elective(s) 3 WAF 226 Specialized Welding Procedures 4 Semester Total 13 Semester 5 Nat. Sci. Elective(s) 4 WAF 227 Basic Fabrication 3 WAF 229 Shape Cutting Operations 3 Writing Elective(s) 3 Semester Total 13 Program Totals 67
