REMEDIES OF THE DEPARTMENT Sample Clauses

REMEDIES OF THE DEPARTMENT. The Department shall be free to invoke any and all remedies permitted under Wisconsin law. In particular, if the Contractor fails to perform as specified in the Contract, the Department may issue a written notice of default providing for at least a thirty (30) business day period in which the Contractor shall have an opportunity to cure, provided that cure is possible, feasible, and approved in writing by the Department. Time allowed for cure of a default shall not diminish or eliminate the Contractor’s liability. If the default remains, after opportunity to cure, then the Department may: (1) exercise any remedy provided in law or in equity and/or (2) terminate
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
REMEDIES OF THE DEPARTMENT. The Department shall be free to invoke any and all remedies permitted under Wisconsin law. In particular, if the Contractor fails to perform as specified in the Contract, the Department may issue a written notice of default providing for at least a thirty (30) business day period in which the Contractor shall have an opportunity to cure, provided that cure is possible, feasible, and approved in writing by the Department. Time allowed for cure of a default shall not diminish or eliminate the Contractor’s liability. If the default remains, after opportunity to cure, then the Department may: (1) exercise any remedy provided in law or in equity and/or (2) terminate Contractor’s Services. If the Contractor fails to remedy any delay or other problem in its performance of the Contract after receiving reasonable notice from the Department to do so, the Contractor shall reimburse the Department for all reasonable costs incurred as a direct consequence of the Contractor’s delay, action, or inaction. In case of failure to deliver Services in accordance with the Contract, or services from other sources as necessary to fulfill the Contract, the Contractor shall be responsible for the additional cost of such services, including purchase price and administrative fees. This remedy shall be in addition to any other legal remedies available to the Department.
Sample 1Sample 2Sample 3See All (4)
REMEDIES OF THE DEPARTMENT. Whenever any cause of which the Department has actual notice referred to in Section 6.01 hereof shall have happened and be continuing, the Department may take any one (1) or more of the following remedial steps:
Sample 1

Related to REMEDIES OF THE DEPARTMENT

  • RESPONSIBILITIES OF THE DEPARTMENT The Department agrees to:

  • Remedies of the Bank Section 5.01. Pursuant to Section 6.02 (p) of the General Conditions, the following additional events are specified:

  • Obligations of the Department a. The Department shall notify Business Associate of a) any limitation in any applicable Notice of Privacy Practices that would affect the use or disclosure of PHI by the Business Associate and b) any changes, revocations, restrictions or permissions by an individual to the use and disclosure of his/her PHI to which the Department has agreed, to the extent such restrictions or limitations may affect the performance of Business Associate’s services on behalf of the Department.

  • Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services.

  • Remedies of the Association Section 5.01. Pursuant to Section 6.02 (h) of the General Conditions, the following additional events are specified:

  • REMEDIES OF THE PARTIES A. If BUYERS fail to timely perform this Agreement, SELLERS may forfeit it as provided in the Iowa Code (Chapter 656), and all payments made shall be forfeited; or, at SELLERS' option, upon thirty days written notice of intention to accelerate the payment of the entire balance because of BUYERS' default (during which thirty days the default is not corrected), SELLERS may declare the entire balance immediately due and payable. Thereafter this agreement may be foreclosed in equity and the Court may appoint a receiver.

  • Monitoring by the Department The Contractor shall permit all persons who are duly authorized by the Department to inspect and copy any records, papers, documents, facilities, goods, and services of the Contractor that are relevant to this Contract, and to interview clients, employees, and sub-contractor employees of the Contractor to assure the Department of satisfactory performance of the terms and conditions of this Contract. Following such review, the Department shall deliver to the Contractor a written report of its finding, and may direct the development, by the Contractor, of a corrective action plan. This provision shall not limit the Department’s termination rights.

  • Remedies for Non-Compliance The Recipient agrees that if FTA determines that the Recipient or a Third Party Participant receiving federal assistance under 49 U.S.C. chapter 53 is not in compliance with 49 C.F.R. part 655, the Federal Transit Administrator may bar that Recipient or Third Party Participant from receiving all or a portion of the federal transit assistance for public transportation it would otherwise receive.

  • Duties of the City City shall make available to Consultant all data and information in the City's possession which City deems necessary to the preparation and execution of the work, and City shall actively aid and assist Consultant in obtaining such information from other agencies and individuals as necessary. The Director may authorize a staff person to serve as his or her representative for conferring with Consultant relative to Consultant's services. The work in progress hereunder shall be reviewed from time to time by City at the discretion of City or upon the request of Consultant. If the work is satisfactory, it will be approved. If the work is not satisfactory, City will inform Consultant of the changes or revisions necessary to secure approval.

  • Remedies for Noncompliance If a Contractor fails to comply with Federal statutes, regulations or the terms and conditions of a Federal award, HUD or the City of Xxxxx may impose additional conditions, as described in 2 CFR 200.207 Specific Conditions. If HUD or the City of Xxxxx determines that noncompliance cannot be remedied by imposing additional conditions, HUD or the City of Xxxxx may take one or more of the following actions, as appropriate in the circumstances:

Time is Money Join Law Insider Premium to draft better contracts faster.