Time Reporting The Employer may require employees to accurately report time worked in accordance with a positive time reporting process as determined by the Agency.
Billing, Payment, Milestones, and Financial Security 6.1 Billing and Payment Procedures and Final Accounting
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
CMI/RAI MDS Report Recognizing the mutual objective of quality resident care, the Employer agrees to meet through the Union Management Committee with the Union as soon as practicable after the receipt of the annual CMI/RAI MDS report. The Employer agrees to provide the Union with staffing levels, and staffing mix information; the impact of related payroll costs on staffing levels and a written notice of the CMI/RAI MDS report for the facility. The purpose of this meeting is to discuss the impact of the CMI/RAI MDS report on the staffing levels in the Home, quality resident care, and provide the Union with an opportunity to make representation in that regard. The parties shall meet as necessary to discuss other changes or workload issues. The parties may invite additional participants to attend the meeting to support constructive review and discussion.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
NASPO ValuePoint Summary and Detailed Usage Reports In addition to other reports that may be required by this solicitation, the Contractor shall provide the following NASPO ValuePoint reports.
SUBMISSION OF THE MONTHLY MI REPORT 4.1 The completed MI Report shall be completed electronically and returned to the Authority by uploading the electronic MI Report computer file to MISO in accordance with the instructions provided in MISO.
Xxxxxxx to Meet Timelines Failure by the Union to comply with the timelines will result in the automatic withdrawal of the grievance. Failure by the Employer to comply with the timelines will entitle the Union to move the grievance to the next step of the procedure.
Project Monitoring Reporting Evaluation A. The Project Implementing Entity shall monitor and evaluate the progress of its activities under the Project and prepare Project Reports in accordance with the provisions of Section 5.08(b) of the General Conditions and on the basis of indicators agreed with the Bank. Each such report shall cover the period of one
Monthly Billing Statements The Engineer shall request reimbursement of costs incurred by submitting the original and one copy of an itemized billing statement in a form acceptable to the State. The Engineer is authorized to submit requests for reimbursement no more frequently than monthly and no later than ninety (90) days after costs are incurred.
