Quality of Food and Beverage Items Sample Clauses

Quality of Food and Beverage Items. 1. Company acknowledges that the primary goal of the Aviation Authority, with regard to the concession operations hereunder is to provide to the public and the air traveler high quality food and beverage items and first class service at reasonable prices. Company further acknowledges the special characteristics of the Orlando air traffic market, which has a very high proportion of tourist travelers, many with small children, who spend considerable time in the South Terminal Complex before departing for their destinations and frequently avail themselves of Company’ services. To ensure that these visitors depart Orlando with the best impression possible of the Airport and the community, the Aviation Authority is unequivocally committed to maintain high quality items, products and services at reasonable prices at all times throughout the term of this Agreement. The Company shall sell only high quality items which shall be comparable in quality to comparable items sold in first class facilities of similar type in the Greater Orlando area.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs

Related to Quality of Food and Beverage Items

  • Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.

  • Glass Or Safety Glazing Material a. We cover:

  • DEMONSTRATIONS/SAMPLES 9.1 Bidders shall demonstrate the exact item(s) proposed within seven (7) calendar days from receipt of such request from the Owners.

  • Ownership and Location of Metering Equipment The Metering Equipment to be constructed, the capability of the Metering Equipment to be constructed, and the ownership thereof, are identified on the attached Schedule C to this ISA.

  • Particular Methods of Procurement of Goods and Works International Competitive Bidding. Goods and works shall be procured under contracts awarded on the basis of International Competitive Bidding.

  • Cooperation on Preventing End User Fraud The Parties agree to cooperate fully with one another to investigate, minimize, prevent, and take corrective action in cases of fraud.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Use of State Facilities Resources and Equipment a. Meeting Space and Facilities. The Employer’s campuses and facilities may be used by the Union to hold meetings subject to the University’s policy and availability of the space. The Employer may provide private space for stewards and/or Union representatives to meet in confidence with those they represent on a space available basis. Staff representatives may reserve and utilize meeting rooms in accordance with University policy and procedure. Such requests will be subject to availability and all applicable fees.

  • Sugar-Sweetened Beverage Prohibition Contractor agrees that it shall not sell, provide, or otherwise distribute Sugar-Sweetened Beverages, as defined by San Francisco Administrative Code Chapter 101, as part of its performance of this Agreement.

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

Time is Money Join Law Insider Premium to draft better contracts faster.