Proposal Schedule Sample Clauses

Proposal Schedule. This schedule shall be the basis for monitoring Design-Builder’s performance of the Work until such time as a Baseline Schedule has been approved by Department in accordance with Section 11.1.2 below.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Proposal Schedule. Contractor represents that the Proposal Schedule (Appendix 5) is an accurate representation of Contractor’s plan for the execution of the Work as of the Effective Date and that Contractor intends to use such Proposal Schedule to execute the Work in compliance with the Contract Documents until the approval of the Baseline Schedule.
Sample 1Sample 2Sample 3See All (4)
Proposal Schedule. The schedule is as follows:  Advertisement Date – October 5, 2023  Proposals Due on PlanetBids – October 26, 2023 by 5:00 p.m.  Proposal Evaluations/Interviews, if necessary – November 2023City Council Contract Award and Selection* - December 2023 *The City expects, but does not guarantee, that the decision on selection of a firm will be made by the City Council on the date indicated above.
Sample 1
Proposal Schedule. HISD desires to complete the proposal process in accordance with the following timeline which is subject to change at the District’s discretion: Timeline October 14, 2016 October 25, 2016 2:00 PM; in Suite 2200, 0000 Xxxxxxx Xxxx, Xxxxxxx, XX 00000 October 31, 2016 10:00 AM November 29, 2016 10:00 AM November 30, 2016 – December 5, 2016 (subject to change) Next regularly scheduled Board meeting after interviews and selection Proposal(s) Selected Approved Evaluation Period RFP Due Last date for questions: Pre-Proposal Conference Release RFP Houston Independent School District Attn: Procurement Services 0000 Xxxx 00XX XXXXXX Xxxxxxx, XX 00000-0000 Email: xxxxxxxx@xxxxxxxxxx.xxx  Go to xxx.xxxxxxxxxx.xxx  Click on “Directory”  Search for “Procurement Services”  *Favorite page*  Click on “See current bid proposals” under ‘Quick Links’  Search for Solicitation project.
Sample 1
Proposal Schedule. The following is the scheduled calendar of events with important dates and times. Dates are subject to change by the Chief Procurement Officer or designee, at their sole discretion. If the Procurement and Contracts Division determines that it is necessary to change these dates/times prior to the Proposal due date, the change will be announced via an addendum. Action: Date: RFP Released April 4, 2016 Pre-Proposal Conference April 21, 2016 @ 10:30 a.m., Local Time Cut-off date for Questions by Respondents April 25, 2016 @ 5:00 p.m., Local Time Proposal Due Date and Time May 5, 2016 @ 2:00 p.m., Local Time Review and Evaluation of Proposals May or June, 2016
Sample 1
Proposal Schedule. The following is the scheduled calendar of events with important dates and times. Dates are subject to change by the Chief Procurement Officer (“CPO”) of the Procurement and Contracts Division or designee, at their sole discretion. If the Procurement and Contracts Division determines that it is necessary to change these dates/times prior to the Proposal due date, the change will be announced via an addendum. Action: Date: RFP Released February 20, 2017 Pre-Proposal Conference March 2, 2017 @ 9:00 a.m., Local Time Cut-off date for Questions by Respondents Monday, March 13, 2017 by 5:00 p.m., Local time Proposal Due Date and Time March 23, 2017 @ 2:00 p.m., Local Time Review and Evaluation of Proposals March /April 2017
Sample 1
Proposal Schedule. The following is the scheduled calendar of events with important dates and times. Dates are subject to change by the Chief Procurement Officer (“CPO”) of the Procurement and Contracts Division or designee, at their sole discretion. If the Procurement and Contracts Division determines that it is necessary to change these dates/times prior to the Proposal due date, the change will be announced via an addendum. Action: Date: RFP Released June 25, 2021 Pre-Proposal Conference July 1, 2021 @ 10:00 am via Teams Meeting Cut-off date for Questions by Respondents July 12, 2021@ 5:00 pm Proposal Due Date and Time July 21, 2021 Review and Evaluation of Proposals August 2021
Sample 1
AutoNDA by SimpleDocs
Proposal Schedule. Applicants must submit a proposal by January 27, 2017 by 4:00 pm. Interviews, if necessary, may be held in early February, 2017. Selection of one or more consultants will occur in early February, 2017, with contract execution within two weeks. The selected consultant will be expected to begin work upon execution of the contract. SOQ Released: January 5, 2017 Pre-submittal meeting: January 17, 2017 Last day to submit questions: January 25, 2017 Deadline to submit SOQ: January 27, 2017 by 4:00 pm Staff review of submittals: January 27, 2017 through February 2, 2017 (if needed) Notification of interviews: February 3, 2017 (if needed) Interviews of firms: February 6, 2017 (if needed) Notification of awarded contract(s): February 6, 2017 or February 8, 2017 Execution of contract(s): by February 15, 2017 Pre-Proposal Conference A pre-proposal conference to discuss this RFP will be held as indicated below: Date: Tuesday, January 17, 2017 Place: Yolo County Community Services Department (Cache Creek Conference room) Time: 9:30 a.m. Location: 000 Xxxx Xxxxxx Xxxxxx Woodland, CA. 95695 At the pre-proposal conference County staff will be available to answer questions about the scope of the services required. Please contact the planner above to let him know if you will be attending. If little or no interest is expressed by firms in attending this pre-proposal meeting, it may be canceled. Questions to answers will be compiled and posted on Bidsync after the conference.
Sample 1
Proposal Schedule. 4. The original, all copies of the proposal, and the separate and sealed cost sheet or bid must be in a sealed envelope, container, or package stating the following on the outside:
Sample 1

Related to Proposal Schedule

  • Submittal Schedule Within sixty days after the Effective Date of the Contract, the Contractor shall prepare and submit a Submittal Schedule for review and approval of the Design Professional. In establishing the Submittal Schedule the Contractor shall take into account large submittal documents that will require longer review times, e.g., submittals with over fifty sheets of drawings. The Design Professional’s approval shall be based on conformance of the Submittal Schedule with the Overall Project Schedule, subject to change from time to time in accordance with the progress of the Work.

  • Additional proposals If the Company at any time during the continuance of this Agreement desires to modify expand or otherwise vary its activities carried on pursuant to this Agreement beyond those specified in any approved proposal, it shall give notice of such desire to the Minister and within 2 months after giving such notice shall submit to the Minister detailed proposals in respect of such modifications expansions or variations and such other matters as the Minister may require. The provisions of clause 4 and 5 (including (for the avoidance of doubt) clause 5(9)) shall apply, the necessary changes being made, to proposals submitted pursuant to this clause.

  • RDO Schedule a) The Schedule of RDO’s to be observed each year will generally be as provided under the VBIA.

  • Preliminary Schedule A preliminary schedule of construction indicating the starting and completion dates of the various stages of the Work, including any information and following any form as may be specified in the Specifications. Once approved by District, this shall become the Construction Schedule. This schedule shall include and identify all tasks that are on the Project’s critical path with a specific determination of the start and completion of each critical path task as well as all Contract milestones and each milestone’s completion date(s) as may be required by the District.

  • Shift Schedule The words "shift schedule" when used in this Agreement shall mean a timetable of the shifts and off days assigned to a position or group of positions which commences at the beginning of a pay period and includes one complete rotation of said shifts.

  • Accrual Schedule The combined accrual schedule is as follows: Completion of Full-Time/pay period Part-Time 1-2 years 4.92 hours .0615 hrs/hr 3 years 5.544 hours .0693 hrs/hr 4-5 years 7.376 hours .0922 hrs/hr 6-7 years 7.696 hours .0962 hrs/hr 8-9 years 8.000 hours .1000 hrs/hr 10-11 years 8.304 hours .1038 hrs/hr 12+ years 8.92 hours .1115 hrs/hr

  • Notice of Work Schedules (a) Work schedules for regular employees shall be posted at least fourteen (14) days in advance of the starting day of a new schedule.

  • Work Schedule Changes 215. It is agreed that pursuant to the exercise of management rights, normal work schedules may be changed without mutual agreement, subject to compliance with other provisions of this Agreement. However, it is agreed that the effects of consequences of such changes are subject to the meet and confer obligation to the extent required by state law.

  • Work Schedules Workweeks and work shifts of different numbers of hours may be established by the Employer in order to meet business and customer service needs, as long as the work schedules meet federal and state laws.

  • Evaluation Schedule CLIENT REFERENCES The Tenderer shall provide details of his performance on each of the previous projects listed in the “Relevant Experience” returnable schedule. “Client Reference Scorecards” will be completed by each of the respective Clients for the projects listed in the “Relevant Experience” returnable schedule. The following are to be completed by the Client and Principal Agent and is to be supported in each case by a letter of award and the works completion certificate. Both Client and Principal Agent must sign and stamp the documents, failure to obtain both signatures and stamps will result in no allocation of points. PROJECT NAME and SCOPE OF WORK: Principal agent: ................................................................................................................................. Client: .. ..............................................................................................................................................

Time is Money Join Law Insider Premium to draft better contracts faster.