Project Work Order Sample Clauses

Project Work Order. Successful Respondent shall, within the time frame specified in such Project Request (and in no event more than five (5) DIR Business Days from receipt of such request unless another time frame is approved by DIR), at no charge to DIR, prepare and deliver to DIR a proposed Project Work Order (each, a "Project Work Order"), as described below. Each proposed Project Work Order prepared by Successful Respondent will contain the following information: (i) a detailed description of the scope of work to be performed by Successful Respondent to complete and implement the Project, including any required Deliverables; (ii) any specific performance standards that will apply to the completion and implementation of such Project, including Successful Respondent’s agreement to meet applicable Service Levels; (iii) an anticipated schedule for completing and implementing the Project and any related Deliverables, including Milestones and credits for failing to achieve Acceptance of Milestones and Deliverables; (iv) a description of the Successful Respondent positions that will be assigned to each activity specified in the Project Work Order, including the location of Successful Respondent Personnel assigned to such positions (i.e., onsite, offsite, onshore) and sufficient detail to allow DIR to audit the assignment and xxxxxxxx related to such Successful Respondent Personnel; (v) a description of the Acceptance Criteria and Acceptance Testing procedures to be used by DIR in connection with any Acceptance Testing of such Project and any related Deliverables and Milestones; (vi) the estimated number of personnel hours needed to complete the Project; (vii) one (1) or more fee quotes, based on the following pricing mechanisms: (a) the applicable hourly rate, in accordance with the Rate Card, (b) if the Project consists of multiple units of work for which there are pre-defined one-time Charges, the number of pre-defined work units multiplied by the applicable pre-defined one-time Charge, or (c) if requested by DIR, a fixed fee or other pricing mechanism. DIR may, at its option, choose which pricing mechanism will apply to the Project. Successful Respondent will not commence performing any services in connection with a Project, and DIR will not be responsible for any Charges applicable to such Project, until the Parties have executed the applicable Project Work Order. Any change to a Project Work Order will be made pursuant to the Change Control Procedure.
Sample 1Sample 2See All (5)
AutoNDA by SimpleDocs
Project Work Order. This Project Work Order (the “PWO”), effective as of [DATE] (the “PWO Effective Date”), is incorporated into and shall be governed by the Agreement for the Manufacturing & Supply of Clinical Trial by and between Takeda Pharmaceutical Company Limited and Myovant Sciences Ltd., (“Myovant”), dated of June 7, 2016. For the purposes of this PWO, “
Sample 1Sample 2
Project Work Order. Each document executed by Consultant and XX Xxxxxxxxxxxxx for the provision of Work, and contains the pricing and other terms and conditions applicable to the project.
Sample 1
Project Work Order. Any change to a Project Work Order will be made pursuant to the Change Control Procedure.
Sample 1
Project Work Order. By submitting a Project Work Order under this Master Services Agreement, Client may request that BIOVEST undertake a Project for Client. Client and BIOVEST shall exercise their mutual best efforts and good faith to finalize and reach agreement on all terms of Client’s requested Project and the Project Work Order submitted by Client. Upon execution of the Project Work Order by both Client and BIOVEST:
Sample 1
Project Work Order. Level 1 The Contractor shall complete Project Work Order Level 1in a timely manner and ensure facilities, ground structures, personal property equipment, and installed equipment and systems are restored to a safe, normal working condition and function properly. Project Work Order Level 1: work that exceeds the service order limit but is estimated to be less than $3,000 in direct labor and direct material costs. Project Work Order Level 1 are completed as specified in the project work order.
Sample 1
Project Work Order. A written order issued by the Contract Administrator directing the Contractor to perform work in accordance with.
Sample 1
AutoNDA by SimpleDocs

Related to Project Work Order

  • Statement of Work The Contractor shall provide the services and staff, and otherwise do all things necessary for or incidental to the performance of work, as set forth below:

  • Project Plan Development of Project Plan Upon the Authorized User’s request, the Contractor must develop a Project Plan. This Project Plan may include Implementation personnel, installation timeframes, escalation procedures and an acceptance plan as appropriate for the Services requested. Specific requirements of the plan will be defined in the RFQ. In response to the RFQ, the Contractor must agree to furnish all labor and supervision necessary to successfully perform Services procured from this Lot. Project Plan Document The Contractor will provide to the Authorized User, a Project Plan that may contain the following items: • Name of the Project Manager, Contact Phone Numbers and E-Mail Address; • Names of the Project Team Members, Contact Phone Numbers and E-Mail Address; • A list of Implementation milestones based on the Authorized User’s desired installation date; • A list of responsibilities of the Authorized User during system Implementation; • A list of designated Contractor Authorized Personnel; • Escalation procedures including management personnel contact numbers; • Full and complete documentation of all Implementation work; • Samples of knowledge transfer documentation; and • When applicable, a list of all materials and supplies required to complete the Implementation described in the RFQ. Materials and Supplies Required to Complete Implementation In the event that there are items required to complete an Implementation, the Contractor may request the items be added to its Contract if the items meet the scope of the Contract. Negotiation of Final Project Plan If the Authorized User chooses to require a full Project Plan, the State further reserves the right for Authorized Users to negotiate the final Project Plan with the apparent RFQ awardee. Such negotiation must not substantively change the scope of the RFQ plan, but can alter timeframes or other incidental factors of the final Project Plan. The Authorized User will provide the Contractor a minimum of five (5) business days’ notice of the final negotiation date. The Authorized User reserves the right to move to the next responsible and responsive bidder if Contractor negotiations are unsuccessful.

  • Work Orders If the Contract is for indefinite quantities of Services, as specified in the Signature Document, all Work will be performed in accordance with properly executed Work Orders.

  • Scope of Work The Contractor has overall responsibility for and shall provide and furnish all materials, equipment, tools and labor as necessary or reasonably inferable to complete the Work, or any phase of the Work, in accordance with the Owner’s requirements and the terms of the Contract Documents.

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Development Work The Support Standards do not include development work either (i) on software not licensed from CentralSquare or (ii) development work for enhancements or features that are outside the documented functionality of the Solutions, except such work as may be specifically purchased and outlined in Exhibit 1. CentralSquare retains all Intellectual Property Rights in development work performed and Customer may request consulting and development work from CentralSquare as a separate billable service.

  • THE WORK The Work comprises the completed construction required by the Contract Documents and includes all labor necessary to produce such construction, and all materials and equipment incorporated or to be incorporated in such construction.

  • Commencement of Work Engineer shall not commence any field work under this Contract until he/she/it has obtained all required insurance and such insurance has been approved by County. As further set out below, Engineer shall not allow any subcontractor/subconsultant(s) to commence work to be performed in connection with this Contract until all required insurance has been obtained and approved and such approval shall not be unreasonably withheld. Approval of the insurance by County shall not relieve or decrease the liability of Engineer hereunder.

  • Production Work The Company may use Outside Entities to perform production work outside the plant and its environs provided the Company demonstrates that it is utilizing plant equipment to the maximum extent consistent with equipment capability and customer requirements and the Company is making necessary capital investments to remain competitive in the steel business and is in compliance with Article Eleven, Section B (Investment Commitment).

  • Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.

Time is Money Join Law Insider Premium to draft better contracts faster.