Project Time Frame Sample Clauses

Project Time Frame. Poinciana and Xxxxxx’x Walk acknowledge that the Restated Poinciana Lease requires Xxxxxx’x Walk to commence vertical construction of the Project within eighteen (18) months after the Approval Date and substantially complete the Project within thirty-six (36) months after commencement of construction of the Project (the “Completion Date”). The Completion Date shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for the Project. The Restated Poinciana Lease provides that the Completion Date shall be automatically extended one day for each day of Unavoidable Delay. The Completion Date may also be extended as provided in the Restated Poinciana Lease. The term “Unavoidable Delay” means delays due to area-wide strikes, acts of God, floods, hurricanes, casualties, fires, act of the public enemy, embargoes, area-wide lack of transportation and area-wide material shortages, and shall not include delays caused by a governmental entity acting in its proprietary or regulatory capacity, or delays caused by lack of available funds.
Sample 1
Project Time Frame. Developer shall commence vertical construction of the Project within eighteen (18) months after the Approval Date and substantially complete the Project within thirty-six (36) months after commencement of construction of the Project (the “Completion Date”). The Completion Date shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for the Project. The Completion Date shall be automatically extended one day for each day of Unavoidable Delays. The term “Unavoidable Delays” means delays due to area-wide strikes, acts of God, floods, hurricanes, casualties, fires, act of the public enemy, embargoes, area-wide lack of transportation and area- wide material shortages, and shall not include delays caused by a governmental entity acting in its proprietary or regulatory capacity, or delays caused by lack of available funds. In the event of the occurrence of any such Unavoidable Delay, the time or times for the performance of the covenants, provisions and agreements of this Lease, shall be extended for the period of delay actually caused by the Unavoidable Delay; provided, however, that the party seeking the benefit of the provisions of this Section 3.4.2 shall, within ten (10) days after such party shall have become aware of such Unavoidable Delay, give written notice to the other party, stating the event purportedly constituting the Unavoidable Delay and as soon as reasonably possible thereafter provide written notice to the other party of the additional period of time required for any performance as a result of the Unavoidable Delay. The failure to provide such notice shall constitute the waiver of right of that party to claim that an Unavoidable Delay has occurred. Any dispute between the Developer and the CRA as to whether an Unavoidable Delay has occurred and/or the duration of the delay caused by the Unavoidable Delay shall be decided by arbitration pursuant to Article XXIII of this Lease at the request of either party. Developer may extend Completion Date, as same may be extended by Unavoidable Delays for an additional twenty-four
Sample 1
Project Time Frame. This is a 36‐month contract. The period of performance is July 12, 2010 through June 30, 2013.
Sample 1
Project Time Frame. Agreement to the terms, and the receipt of the Initial Payments are required prior to project start. Project Start date is upon signing this agreement. Project Completion Time Frame is 8-12 weeks from Project Start Date. Project Time Frame is an estimate based on next-day feedback, where feedback is needed. Delays in feedback beyond next-day will push the Time Frame back the same number of days as has been delayed.
Sample 1
Project Time Frame. Borrower shall use commercially reasonable efforts to achieve the timeframe outlined in the associated Grant Application.
Sample 1
AutoNDA by SimpleDocs
Project Time Frame. 2.1 The parties anticipate that the following steps will be taken to complete the Project and that each step will be taken by the dates specified:
Sample 1

Related to Project Time Frame

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Work Schedule A 4/10 work schedule is four (4) ten hour days in a seven (7) day period, for a total of forty (40) hours per week.

  • Project Budget A Project Budget shall be prepared and maintained by Grantee. The Project Budget shall detail all costs for which the Grant will be used during each calendar month of the Term. The Project Budget must be approved in writing by the Project Monitor. Grantee shall carry out the Project and shall incur costs and make disbursements of funds provided hereunder by the Sponsor only in conformity with the Project Budget. The current approved Project Budget is contained in Attachment B. Said Project Budget may be revised from time to time, but no Project Budget or revision thereof shall be effective unless and until the same is approved in writing by Project Monitor. The funds granted under this Grant Contract cannot be used to supplant (replace) other existing funds.

  • Construction Budget The total amount indicated by the District for the Project plus all other costs, including design, construction, administration, financing, and all other costs.

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2

  • Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.

  • Project Completion Part 1 – Material Completion

  • Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.

  • Contract Schedule The information set forth in the Contract Schedule is true and correct.

  • Project Scope The physical scope of the Project shall be limited to only those capital improvements as described in Appendix A of this Agreement. In the event that circumstances require a change in such physical scope, the change must be approved by the District Committee, recorded in the District Committee's official meeting minutes, and provided to the OPWC Director for the execution of an amendment to this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.