PROJECT MANAGEMENT FIRM–CONSTRUCTION MANAGEMENT SERVICES Sample Clauses

PROJECT MANAGEMENT FIRM–CONSTRUCTION MANAGEMENT SERVICES. The Project Management Firm accepts the relationship of trust and confidence established between their firm and the Owner by this agreement. In performing the construction management duties hereunder, the Project Management Firm covenants with the Owner to furnish the best standard of care, construction skill, judgment, and the construction industries accepted requisites for construction management services in furthering the interests of the Owner. The Project Management Firm agrees to perform the obligations hereunder using efficient Project construction management business administration and superintendence, and using their best construction management efforts to facilitate the expeditious and economical completion of the Project scope of work requirements consistent with the interest of the Owner. The Project Management Firm acknowledges that the Owner is the first interpreter of the Project Management Firm’s construction management services and performance under this Contract. The Owner reserves the right to assign to the Project Management Firm, additional duties and responsibilities with respect to the administration of separate Contracts between the Owner and the Prime Professional Services Contractor (Architect/Engineer), other than asbestos or hazardous materials removal and disposal. In the event that the Owner assigns such additional administrative duties and responsibilities to the Project Management Firm, the Project Management Firm shall be entitled to a monetary adjustment by the Owner in compensation fee as stated in the Article 5, Compensation text of this Contract. In the event the Owner makes an assignment of administrative duties to the Project Management Firm, such assignment shall not relieve either the Owner or the Prime Professional Services Contractor (Architect/Engineer) of any duties or obligations each has to the other under this Contract, nor shall such assignment create in the Project Management Firm any duties and obligations toward the Owner under the separate Contract with the Prime Professional Services Contractor (Architect/Engineer), except those pertaining to the administration of this Contract. Any additional Prime Professional Services Contractor (Architect/Engineer) services necessary to complete this Project shall be employed by the Owner. No increase in compensation fee to the Project Management Firm will be allowed unless there is a material change made to the Project scope of work requirements as described in the...
Sample 1
AutoNDA by SimpleDocs

Related to PROJECT MANAGEMENT FIRM–CONSTRUCTION MANAGEMENT SERVICES

  • Project Management Services Contractor shall provide business analysis and project management services necessary to ensure technical projects successfully meet the objectives for which they were undertaken. Following are characteristics of this Service:

  • Project Management Project Management Institute (PMI) certified project manager executing any or all of the following: • Development of Project Charter • Development of project plan and schedule • Coordination and scheduling of project activities across customer and functional areas • Consultation on operational and infrastructure requirements, standards and configurations • Facilitate project status meetings • Timely project status reporting • Address project issues with functional areas and management • Escalation of significant issues to customers and executive management • Manage project scope and deliverable requirements • Document changes to project scope and schedule • Facilitate and document project closeout

  • Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.

  • CONSTRUCTION MANAGER’S SERVICES The services which the Construction Manager shall provide include, but are not limited to, those described or specified herein. The services described or specified shall not be deemed to constitute a comprehensive specification having the effect of excluding services not specifically mentioned.

  • Development Services During the term of this Agreement, the Provider agrees to provide to or on behalf of the Port the professional services and related items described in Exhibit A (collectively, the “Development Services”) in accordance with the terms and conditions of this Agreement. The Provider specifically agrees to include at least one Port representative in any economic development negotiations or discussions in which the Provider is involved concerning (i) a port-related business prospect or (ii) a business transaction which will ultimately require Port involvement, financial or otherwise.

  • Project Management and Coordination The Engineer shall coordinate all subconsultant activity to include quality of and consistency of work and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.

  • Construction Administration Services The Engineer shall perform construction administration services during construction as necessary. Such services shall, as part of the services to be rendered for the Engineer's established fee, include as much of the Engineer's professional services and the services of the Engineer's consultants as the State deems necessary for the well-being of the project and efficient prosecution of the construction work, but shall not include the Engineer's undertaking continuous on-site observation of the work. If the Engineer fails to perform such duties in a conscientious and reasonable manner, the State may exercise its right to terminate this contract as hereinafter provided in Section T. Additionally, it is understood and agreed to by the Engineer and the State that the duties of the Engineer shall include, but not be limited to, the following services:

  • Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.

  • Project Management Plan 1 3.4.1 Developer is responsible for all quality assurance and quality control 2 activities necessary to manage the Work, including the Utility Adjustment Work.

  • Program Management 1.1.01 Implement and operate an Immunization Program as a Responsible Entity

Time is Money Join Law Insider Premium to draft better contracts faster.