Project Completion Date. It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
Project Completion Date. The Applicant shall complete the Project by the last Milestone End Date specified in Schedule B. ("Project Completion Date"). If the Applicant terminates or stops work on its part of the Project for any reason prior to the Project Completion Date, it shall provide Notice to Alberta Innovates immediately.
Project Completion Date. The Recipient agrees to carry out the Project in a diligent and professional manner using qualified personnel, and complete same on or before the Project Completion Date.
Project Completion Date. If the Project, in the sole judgment of the Department, is not completed on or before the Project Completion Date.
Project Completion Date. The approved grant activities must be completed by June 30, 2023 (“Project Completion Date”). By the Project Completion Date, all Project activities must be completed, including submission of the Project Completion Report that is the attached Exhibit D and all cash requests.
Project Completion Date. 7.1 The Organization will complete the Project on or before April 30, 2004 (the “Project Completion Date”).
Project Completion Date. The Project Completion Date shall have occurred.
Project Completion Date. (11) The County where the Project is located or, if it is located in more than one county, where it is primarily located.
Project Completion Date. 11.2.1. On or after the Effective Date, the Operator shall undertake Furnishing and Fixture works in the Project. The end of forty-five days from the Effective Date shall be the end of Completion Period (the “Scheduled Commercial Operations Date”) for completion of furnishings and the Operator agrees and undertakes that the furnishing, fixtures etc. of the Project Facility shall be completed on or before the Scheduled Commercial Operations Date.
Project Completion Date. It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant and the Service Provider of its decision to terminate as soon as reasonably practical and shall advise the Applicant and the Service Provider of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant or the Service Provider for any Project Costs incurred after the effective date of termination and may require the Applicant and/or the Service Provider to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
