Professional Indemnity – Single-Project Professional Indemnity - SPPI Sample Clauses

Professional Indemnity – Single-Project Professional Indemnity - SPPI covering the Project Designer's and/or the Company's and/or the State of Israel's and/or the ministry of transport's and road safety in Israel and/or Sub-contractors and anyone acting on their behalf liability under any and all Laws, for any act, and/or omission, arising out of a breach of professional indemnity with Limits of liability of USD 10,000,000 per occurrence and in the aggregate for the annual insurance period. The insurance granted under this clause shall not include any restriction and/or exclusion concerning: employees' dishonesty and delay, loss of use, postponement or delay in performance of the services, loss of documents, the insured's undertakings for management and/or provision of services and/or their regularization and/or ordering materials and their regularization, financial and consequential damages, and supervision including overall supervision. The insurance will include a retroactive date that is not later than the beginning of services activity of the Project Designer's and/or any person on his behalf. The insurance will include a discovery period of 84 months starting from the expiry of the insurance period, unless the Project Designer maintains another insurance policy conforming to the requirements of abovementioned. Retroactive date from the date of commencement of provision of the services as stated. In the event that the insurance with our Company is cancelled other than as a result of non-payment of the premiums or if it is not renewed for any reason, it is agreed that the period for disclosure of damage and claims will be extended for a further 6 months from the date of expiry of the insurance with our Company and any incident that occurred during the period of insurance and of which notice is given within the extended period of disclosure will be deemed to all intents and purposes as an incident of which notice was given during the period of insurance. Period: from until Discovery period: from _ until General provisions:
Sample 1
AutoNDA by SimpleDocs

Related to Professional Indemnity – Single-Project Professional Indemnity - SPPI

  • G2 Professional Indemnity The Contractor shall effect and maintain appropriate professional indemnity insurance cover during the Contract Period and shall ensure that all agents, professional consultants and sub-contractors involved in the supply of the Services do the same. To comply with its obligations under this clause and as a minimum, the Contractor shall ensure professional indemnity insurance held by the Contractor and by any agent, sub-contractor or consultant involved in the supply of the Services has a limit of indemnity of not less than £500,000 for each individual claim [or such higher limit as the Client may reasonably require (and as required by law) from time to time]. Such insurance shall be maintained for a minimum of 6 (six) years following the expiration or earlier termination of the Contract.

  • Professional Indemnity Insurance A policy of insurance to cover claims made against the insured for: civil liability for breach of professional duty (whether owed in contract or otherwise); and unintentional breaches of third party intellectual property, by the Contractor or its subcontractors in carrying out the Contractor's Activities.

  • Professional Indemnity C11.1 The Contractor shall effect and maintain appropriate professional indemnity insurance cover of an amount not less than £5,000,000 per incident or such higher amount as the Authority may reasonably require during the Contract Period and shall ensure that all Contractor’s Personnel involved in the supply of the Services do the same. Such insurance shall be maintained for a minimum of six (6) years following the expiration or earlier termination of the Contract, unless the Contract has been entered into by way of a deed in which event the period shall be twelve (12) years.

  • Additional Indemnity Provisions A. CONTRACTOR AND SYSTEM AGENCY AGREE TO FURNISH TIMELY WRITTEN NOTICE TO EACH OTHER OF ANY INDEMNITY CLAIM. CONTRACTOR SHALL BE LIABLE TO PAY ALL COSTS OF DEFENSE, INCLUDING ATTORNEYS’ FEES.

  • Additional Indemnification (a) Notwithstanding any limitation in Sections 2, 3 or 4, the Company shall indemnify Indemnitee to the fullest extent permitted by applicable law if Indemnitee is, or is threatened to be made, a party to or a participant in any Proceeding (including a Proceeding by or in the right of the Company to procure a judgment in its favor) against all Expenses, judgments, fines and amounts paid in settlement actually and reasonably incurred by Indemnitee or on his or her behalf in connection with the Proceeding or any claim, issue or matter therein.

  • Additional Indemnity Obligations Consultant shall defend, with counsel of Town’s choosing and at Consultant's own cost, expense and risk, any and all claims, suits, actions or other proceedings of every kind covered by Section 3.5.6.1 that may be brought or instituted against Town or its directors, officials, officers, employees, volunteers and agents. Consultant shall pay and satisfy any judgment, award or decree that may be rendered against Town or its directors, officials, officers, employees, volunteers and agents as part of any such claim, suit, action or other proceeding. Consultant shall also reimburse Town for the cost of any settlement paid by Town or its directors, officials, officers, employees, agents or volunteers as part of any such claim, suit, action or other proceeding. Such reimbursement shall include payment for Town's attorney's fees and costs, including expert witness fees. Consultant shall reimburse Town and its directors, officials, officers, employees, agents, and/or volunteers, for any and all legal expenses and costs incurred by each of them in connection therewith or in enforcing the indemnity herein provided. Consultant's obligation to indemnify shall not be restricted to insurance proceeds, if any, received by the Town, its directors, officials officers, employees, agents, or volunteers.

  • Train Operator indemnity The Train Operator shall indemnify Network Rail against all Relevant Losses resulting from:

  • Indemnity for Professional Liability When the law establishes a professional standard of care for CONTRACTOR’s services or if the services or a portion of the services performed by the CONTRACTOR involves the use of professional knowledge, and to the fullest extent permitted by law, CONTRACTOR shall defend, indemnify and hold harmless COMMISSION, its officials, officers, directors, employees, servants, designated volunteers and agents serving as independent contractors in the role of COMMISSION officials (collectively “Indemnitees”), from and against any liability, claim, damage, demand, suit, cause of action, proceeding, judgment, penalty, lien, loss, expense or cost of any kind, including reasonable fees of accountants, attorneys and other professionals, and all costs associated therewith (collectively, “damages”), whether actual, alleged or threatened, arising out of, pertaining to, or relating to any negligent or wrongful act, error or omission of CONTRACTOR, its officials, officers, directors, agents, employees, subcontractors, or any entity or individual that CONTRACTOR bears legal liability thereof, in the performance of professional services under this Contract. CONTRACTOR shall defend Indemnitees in any action or actions filed in connection with any such damages with counsel of COMMISSION’s choice and shall pay all costs and expenses, including actual attorney’s fees, incurred in connection with such defense.

  • Environmental Indemnification Borrower shall, at its sole cost and expense, protect, defend, indemnify, release and hold harmless the Indemnified Parties from and against any and all Losses and costs of Remediation (whether or not performed voluntarily), engineers' fees, environmental consultants' fees, and costs of investigation (including but not limited to sampling, testing, and analysis of soil, water, air, building materials and other materials and substances whether solid, liquid or gas) imposed upon or incurred by or asserted against any Indemnified Parties, and directly or indirectly arising out of or in any way relating to any one or more of the following: (a) any presence of any Hazardous Substances in, on, above, or under the Property; (b) any past, present or threatened Release of Hazardous Substances in, on, above, under or from the Property; (c) any activity by Borrower, any Person affiliated with Borrower or any tenant or other user of the Property in connection with any actual, proposed or threatened use, treatment, storage, holding, existence, disposition or other Release, generation, production, manufacturing, processing, refining, control, management, abatement, removal, handling, transfer or transportation to or from the Property of any Hazardous Substances at any tine located in, under, on or above the Property; (d) any activity by Borrower, any Person affiliated with Borrower or any tenant or other user of the Property in connection with any actual or proposed Remediation of any Hazardous Substances at any time located in, under, on or above the Property, whether or not such Remediation is voluntary or pursuant to court or administrative order, including but not limited to any removal, remedial or corrective action; (e) any past or present non-compliance or violations of any Environmental Laws (or permits issued pursuant to any Environmental Law) in connection with the Property or operations thereon, including but not limited to any failure by Borrower, any Affiliate of Borrower or any tenant or other user of the Property to comply with any order of any Governmental Authority in connection with any Environmental Laws; (f) the imposition, recording or filing of any Environmental Lien encumbering the Property; (g) any administrative processes or proceedings or judicial proceedings in any way connected with any matter addressed in Article 8 and this SECTION 9.4; (h) any past, present or threatened injury to, destruction of or loss of natural resources in any way connected with the Property, including but not limited to costs to investigate and assess such injury, destruction or loss; (i) any acts of Borrower or other users of the Property in arranging for disposal or treatment, or arranging with a transporter for transport for disposal or treatment, of Hazardous Substances owned or possessed by such Borrower or other users, at any facility or incineration vessel owned or operated by another Person and containing such or any similar Hazardous Substance; (j) any acts of Borrower or other users of the Property, in accepting any Hazardous Substances for transport to disposal or treatment facilities, incineration vessels or sites selected by Borrower or such other users, from which there is a Release, or a threatened Release of any Hazardous Substance which causes the incurrence of costs for Remediation; (k) any personal injury, wrongful death, or property damage arising under any statutory or common law or tort law theory, including but not limited to damages assessed for the maintenance of a private or public nuisance or for the conducting of an abnormally dangerous activity on or near the Property; and (1) any misrepresentation or inaccuracy in any representation or warranty or material breach or failure to perform any covenants or other obligations pursuant to Article 8. Notwithstanding the foregoing, Borrower shall not be liable under this SECTION 9.4 for any Losses or costs of Remediation to which the Indemnified Parties may become subject to the extent such Losses or costs of Remediation arise by reason of the gross negligence, illegal acts, fraud of willful misconduct of the Indemnified Parties. This indemnity shall survive any termination, satisfaction or foreclosure of this Security Instrument, subject to the provisions of SECTION 10.5.

  • LEGAL INDEMNIFICATION 20.01 Subject to the other provisions of this Article, a member charged with and finally acquitted of a criminal or statutory offence, because of acts done while on duty in the attempted performance in good faith of his/her duties as a member of the service shall be indemnified for the necessary and reasonable legal costs incurred in the defence of such charges.

Time is Money Join Law Insider Premium to draft better contracts faster.