Procurement, Installation, Start-Up Sample Clauses

Procurement, Installation, Start-Up. RES will act as a turn-key general contractor assuming total responsibility for the procurement of labor and material for installation and start-up of the Equipment, including, but not limited to, selecting subcontractors in concert with Customer (a list of subcontractors for major work items is set forth in Schedule A); awarding subcontracts; receiving and evaluating submitted drawings on the Equipment; progress inspections during installation; developing and presenting subcontractor punch lists after each inspection; receiving and evaluating record drawings; and operation and maintenance manuals from subcontractors; providing for training of Customer personnel on proper operation of the newly installed Equipment; and final inspection and recommendation for approval to the Customer for acceptance of the Equipment. Notwithstanding the foregoing, the Customer will have the sole right to make the final decision as to acceptance of Equipment and issuance of the Certificate of Acceptance for the Work.
Sample 1
AutoNDA by SimpleDocs
Procurement, Installation, Start-Up. RES will act as a turn-key general contractor assuming total responsibility for the procurement of labor and material for installation and start-up of the Equipment, including, but not limited to, selecting subcontractors in concert with Customer (a list of subcontractors for major work items is set forth in Schedule A); awarding subcontracts; receiving and evaluating submitted drawings on the Equipment; progress inspections during installation; developing and presenting subcontractor punch lists after each inspection; receiving and evaluating record drawings; and operation and maintenance manuals from subcontractors; providing for training of Customer personnel on proper operation of the newly installed Equipment; and final inspection and recommendation for approval to the Customer for acceptance of the Equipment. Notwithstanding the foregoing, the Customer will have the sole right to make the final decision as to acceptance of Equipment and issuance of the Certificate of Acceptance for the Work. Included with Schedule A is a list of drawings and specifications for all of the Equipment and Work to be procured and installed by RES.
Sample 1

Related to Procurement, Installation, Start-Up

  • Equipment Installation In order to meet its obligations under this Agreement, a Party that owns, rents, or leases equipment (the equipment owner) may require installation of such equipment on property owned by another Party (the property owner), provided that the property is being used for an electric utility purpose and that the property owner shall not be required to do so if it would thereby be prevented from performing its own obligations or exercising its rights under this Agreement.

  • Delivery & Installation a) Subject to the conditions of the contract, the delivery of the goods and completion of the related services shall be in accordance with the delivery and completion schedule specified in the bidding document. The details of supply/ shipping and other documents to be furnished by the successful/ selected bidder are specified in the bidding document and/ or contract.

  • Licenses for Permanent Installation The contractor must comply with all State mandatory licensing requirements prior to installation. Questions on licensing requirements should be directed to the State Licensing Board. Contractor must furnish and install all furniture and materials in compliance with all applicable codes, whether local, state, or federal; and that all permits or licenses required for installation will be obtained without cost to the State.

  • Delivery/Installation Instructions Due to the varying locations and circumstances involved in deliveries and installations, all deliveries and installations will be quoted on a project by project basis. All installation, labor, and or delivery charges must be shown as a separate line item on quotes and invoices. One of the following delivery methods must be specified on every Agency Purchase Order:

  • Software Installation The AGENCY shall request approval in writing from the COUNTY prior to installation of any software on COUNTY computer equipment. All software installations must be supervised by COUNTY technical support staff and proof of licensing is required. Upon completion, the AGENCY is responsible for reconfiguring the computers back to the original state.

  • Provisioning Line Splitting and Splitter Space 3.8.1 The Data LEC, Voice CLEC or BellSouth may provide the splitter. When EZ Phone or its authorized agent owns the splitter, Line Splitting requires the following: a non-designed analog Loop from the serving wire center to the NID at the End User’s location; a collocation cross connection connecting the Loop to the collocation space; a second collocation cross connection from the collocation space connected to a voice port; the high frequency spectrum line activation, and a splitter. The Loop and port cannot be a Loop and port combination (i.e. UNE-P), but must be individual stand-alone Network Elements. When BellSouth owns the splitter, Line Splitting requires the following: a non designed analog Loop from the serving wire center to the NID at the End User’s location with CFA and splitter port assignments, and a collocation cross connection from the collocation space connected to a voice port.

  • Provisioning of High Frequency Spectrum and Splitter Space 3.2.1 BellSouth will provide <<customer_name>> with access to the High Frequency Spectrum as follows:

  • Construction Staking Contractor shall avoid careless or negligent damage to construction stakes, flags, or marks. If such damage occurs, Contractor shall be required to replace stakes necessary to construc- tion. Contractor’s replacement staking shall be approved by Forest Service. Alternatively, upon Contractor’s request, Contracting Officer may agree to perform such work under E.2.1.8. When A.7 shows that construction stakes are to be set by Forest Service after clearing, Contractor shall submit to Forest Service a written schedule for clearing, construction staking, and construction that will provide Forest Service a reasonable period for setting construction stakes. Time for setting construction stakes may be modified by written agreement. If Forest Service performs construction staking for Specified Roads, timing of such staking shall permit Contrac- tor’s clearing and other construction activity to proceed without hindrance or delay, provided Contractor’s construction activity is reasonably consistent with needs identified in Contractor’s Operating Schedule or amendments thereto. Should Forest Service be unable to perform construction staking in such reasonable period, upon written agree- ment, Contractor shall assume the responsibility for construction staking for agreed upon portions of Specified Roads. In such event, Contracting Officer shall revise:

  • No Installing Generator Not to install or keep or run any generator in the Said Apartment.

  • Electrical Installations 3.1 Wiring and accessories for lighting of Common Areas.

Time is Money Join Law Insider Premium to draft better contracts faster.