Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Interest Amount Unless otherwise specified in Paragraph 13 and subject to Paragraph 4(a), in lieu of any interest, dividends or other amounts paid or deemed to have been paid with respect to Posted Collateral in the form of Cash (all of which may be retained by the Secured Party), the Secured Party will Transfer to the Pledgor at the times specified in Paragraph 13 the Interest Amount to the extent that a Delivery Amount would not be created or increased by that Transfer, as calculated by the Valuation Agent (and the date of calculation will be deemed to be a Valuation Date for this purpose). The Interest Amount or portion thereof not Transferred pursuant to this Paragraph will constitute Posted Collateral in the form of Cash and will be subject to the security interest granted under Paragraph 2.
Payment Date An amount calculated as being due in respect of any Early Termination Date under Section 6(e) will be payable on the day that notice of the amount payable is effective (in the case of an Early Termination Date which is designated or occurs as a result of an Event of Default) and on the day which is two Local Business Days after the day on which notice of the amount payable is effective (in the case of an Early Termination Date which is designated as a result of a Termination Event). Such amount will be paid together with (to the extent permitted under applicable law) interest thereon (before as well as after judgment) in the Termination Currency, from (and including) the relevant Early Termination Date to (but excluding) the date such amount is paid, at the Applicable Rate. Such interest will be calculated on the basis of daily compounding and the actual number of days elapsed.
PURCHASE PRICE & PAYMENT The total Purchase Price for the Property is the amount of the successful bid for the parcel at public auction.
Returned Payment Fee If your account is subject to a Returned Payment Fee, the fee will be charged to your account when a payment is returned for any reason.