Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner.
Preliminary Schedule A preliminary schedule of construction indicating the starting and completion dates of the various stages of the Work, including any information and following any form as may be specified in the Specifications. Once approved by District, this shall become the Construction Schedule. This schedule shall include and identify all tasks that are on the Project’s critical path with a specific determination of the start and completion of each critical path task as well as all Contract milestones and each milestone’s completion date(s) as may be required by the District.
Preliminary Engineering In order to receive City review and approval of the Extensions, Developer shall furnish two (2) copies of the plat map, topographic map and proposed roads profile sheets in electronic format prior to the City’s ordering of the engineering plans from its Engineer. The contour elevation and road profile elevations shall be referenced to NAVD ‘88 datum. In the event Developer’s engineer prepares the construction plans and specifications, the above information shall be a part of the extension construction plans to be reviewed and approved by the City’s Engineer. The final plat map shall be to the scale of 1-inch = 20 feet. The contour map shall have a scale of 1-inch = 20 feet and contour intervals of two (2) feet or less. The road profile sheets shall be to the scale of 1-inch = 20 feet. Developer shall provide a minimum of one benchmark, datum being NAVD ‘88, on the project site; and the elevation and location of the benchmark shall be indicated on the maps furnished by Developer.
Project contract 1. For each approved project a project contract shall be concluded between the Programme Operator and the Project Promoter.
Preliminary Cost Estimate Consulting Engineer/Architect shall furnish City an estimate of probable Construction Cost based on the preliminary design. Consulting Engineer/Architect's estimate of probable Construction Cost is to be made on the basis of Consulting Engineer/Architect's experience and qualifications and represent Consulting Engineer/Architect's best judgment as an experienced and qualified design professional, familiar with the construction industry.
Construction Contract If federal funds are included as part of the financing of the non-OPWC portion of the Project, federal law may prevail, including, but not limited to, application of Xxxxx Xxxxx prevailing wage rates, the Xxxxxxxx “Anti-Kickback” Act, the Contract Work Hours and Safety Standards Act, and any federal environmental regulations. Recipient is solely responsible for ensuring compliance with federal requirements applicable to its Local Subdivision Contribution. Notwithstanding the above, the following provisions apply to construction contracts under this Agreement:
Construction Contracts Item A: Enter the total dollar amount of all contacts awarded on the project/ program. Item B: Enter the total dollar amount of contracts connected with this project/program that were awarded to Section 3 businesses.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Preliminary Cost Estimates The Engineer shall develop a preliminary cost estimate using the Average Low Bid Unit Price. The Engineer shall estimate the total project cost including preliminary engineering, final engineering, right-of-way (ROW) acquisition, environmental compliance and mitigation, construction, utility relocation, and construction engineering inspection (CEI).
Construction Contract Documents The Construction Contract Documents shall consist of the plans and specifications prepared by the Engineer, and any addenda and change orders thereto, and the Owner-Contractor Agreement, all of which shall be compatible and consistent with this Agreement.
