Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Forecasting Requirements for Trunk Provisioning Within ninety (90) days of executing this Agreement, Reconex shall provide Verizon a two (2) year traffic forecast. This initial forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Local Interconnection Trunk groups over the next eight (8) quarters. The forecast shall be updated and provided to Verizon on an as-needed basis but no less frequently than semiannually. All forecasts shall comply with the Verizon CLEC Interconnection Trunking Forecast Guide and shall include, at a minimum, Access Carrier Terminal Location (“ACTL”), traffic type (Local Traffic/Toll Traffic, Operator Services, 911, etc.), code (identifies trunk group), A location/Z location (CLLI codes for Reconex-IPs and Verizon-IPs), interface type (e.g., DS1), and trunks in service each year (cumulative).
Grievance Description 80. The Union and the City agree that the following guidelines will be used in the submission of grievances.
GRIEVANCE REPORT Attachment I (Grievance Report) will be used in the processing of all grievances.
Contractor Sales Reporting Vendor Management Fee Contractor Reports Master Contract Sales Reporting. Contractor shall report total Master Contract sales quarterly to Enterprise Services, as set forth below. Master Contract Sales Reporting System. Contractor shall report quarterly Master Contract sales in Enterprise Services’ Master Contract Sales Reporting System. Enterprise Services will provide Contractor with a login password and a vendor number. The password and vendor number will be provided to the Sales Reporting Representative(s) listed on Contractor’s Bidder Profile. Data. Each sales report must identify every authorized Purchaser by name as it is known to Enterprise Services and its total combined sales amount invoiced during the reporting period (i.e., sales of an entire agency or political subdivision, not its individual subsections). The “Miscellaneous” option may be used only with prior approval by Enterprise Services. Upon request, Contractor shall provide contact information for all authorized purchasers specified herein during the term of the Master Contract. If there are no Master Contract sales during the reporting period, Contractor must report zero sales. Due dates for Master Contract Sales Reporting. Quarterly Master Contract Sales Reports must be submitted electronically by the following deadlines for all sales invoiced during the applicable calendar quarter: For Calendar Quarter Ending Master Contract Sales Report Due March 31: April 30 June 30: July 31 September 30: October 31 December 31: January 31 Vendor Management Fee. Contractor shall pay to Enterprise Services a vendor management fee (“VMF”) of 0.74 percent on the purchase price for all Master Contract sales (the purchase price is the total invoice price less applicable sales tax). The sum owed by Contractor to Enterprise Services as a result of the VMF is calculated as follows: Amount owed to Enterprise Services = Total Master Contract sales invoiced (not including sales tax) x .0074. The VMF must be rolled into Contractor’s current pricing. The VMF must not be shown as a separate line item on any invoice unless specifically requested and approved by Enterprise Services. Enterprise Services will invoice Contractor quarterly based on Master Contract sales reported by Contractor. Contractors are not to remit payment until they receive an invoice from Enterprise Services. Contractor’s VMF payment to Enterprise Services must reference this Master Contract number, work request number (if applicable), the year and quarter for which the VMF is being remitted, and the Contractor’s name as set forth in this Master Contract, if not already included on the face of the check. Failure to accurately report total net sales, to submit a timely usage report, or remit timely payment of the VMF, may be cause for Master Contract termination or the exercise of other remedies provided by law. Without limiting any other available remedies, the Parties agree that Contractor’s failure to remit to Enterprise Services timely payment of the VMF shall obligate Contractor to pay to Enterprise Services, to offset the administrative and transaction costs incurred by the State to identify, process, and collect such sums. the sum of $200.00 or twenty-five percent (25%) of the outstanding amount, whichever is greater, or the maximum allowed by law, if less. Enterprise Services reserves the right, upon thirty (30) days advance written notice, to increase, reduce, or eliminate the VMF for subsequent purchases, and reserves the right to renegotiate Master Contract pricing with Contractor when any subsequent adjustment of the VMF might justify a change in pricing.
Billing Specifications 55.6.1 The Parties agree that billing requirements and outputs will be consistent with the Ordering & Billing Form (OBF) and also with Telcordia Technologies Billing Output Specifications (BOS).
Technical Standards Applicable to a Wind Generating Plant i. Low Voltage Ride-Through (LVRT) Capability A wind generating plant shall be able to remain online during voltage disturbances up to the time periods and associated voltage levels set forth in the standard below. The LVRT standard provides for a transition period standard and a post-transition period standard.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
