Pre-Award Conferences Sample Clauses

Pre-Award Conferences. The CM, with the assistance of the A/E and the COUNTY, shall gather documentation for contract execution from apparent successful Bidders which may occur at pre-award conferences with such Bidders. Upon the failure of a Bidder to provide such documentation in a timely manner, the CM shall assist the COUNTY in considering whether an extension of time for submitting such documentation is appropriate.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Pre-Award Conferences. The Associate shall gather documentation for contract execution from apparently successful Bidders which may occur at pre-award conferences with such Bidders. Upon the failure of a Bidder to provide such documentation in a timely manner, the Associate shall assist the University in considering whether an extension of time for submitting such documentation is appropriate.
Sample 1Sample 2
Pre-Award Conferences. 6.6.1 The A/E shall conduct pre-award conferences with the apparent successful Bidder and shall assist the Contracting Authority to gather documentation for contract execution from such Bidder.
Sample 1
Pre-Award Conferences. SitelogIQ, with the assistance of the Architect, shall gather documentation for contract execution from apparently successful bidders which may occur at Pre-Award Conferences with such bidders. Upon the failure of a bidder to provide such documentation in a timely manner, SitelogIQ shall assist the School District in considering whether an extension of time for submitting such documentation is appropriate.
Sample 1

Related to Pre-Award Conferences

  • POST AWARD MEETING Within ten (10) days after receipt of notification of award of bid, Contractor shall meet with the County’s representative(s) to discuss job procedures and scheduling.

  • Pre-Award Costs Pre-award costs are those incurred prior to the effective date of the award directly pursuant to the negotiation and in anticipation of the award where such costs are necessary to comply with the proposed delivery schedule or period of performance. Such costs are allowable only to the extent that they would have been allowable if incurred after the date of the award and only with the prior written approval of the Department.

  • System for Award Management (XXX) XXX.gov)

  • System for Award Management (XXX) and Data Universal Numbering System (DUNS) Requirements.

  • System for Award Management (XXX) Requirement Alongside a signed copy of this Agreement, Grantee will provide Florida Housing with a XXX.xxx proof of registration and Commercial and Government Entity (CAGE) number. Grantee will continue to maintain an active XXX registration with current information at all times during which it has an active award under this Agreement.

  • Award Criteria 40.1 The Procuring Entity shall award the Contract to the successful tenderer whose tender has been determined to be the Lowest Evaluated Tender in accordance with procedures in Section 3: Evaluation and Qualification Criteria.

  • Service Award Named Plaintiff may apply to the Court for a service award of up to ten thousand dollars ($10,000). Subject to the Court’s approval, the service award shall be paid from the Settlement Fund ten (10) days after the Effective Date.

  • Service Awards In consideration of the provision of services, COMPANY to pay EMPLOYEE, as compensation; The gross amount of RMB annually calculated at the rate of twelve (12) equal monthly installments consecutively of RMB each.

  • Performance Meetings During a meeting on performance, the parties will:

  • Performance Orders A Performance Order:

Time is Money Join Law Insider Premium to draft better contracts faster.