POSSESSION OF PREMISES Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.
POSSESSION OF PROPERTY Possession of the Property free and clear of all uses and encroachments, except the Permitted Exceptions, shall be delivered to Purchaser at closing.
POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
General Description of Land Use 3.3.1 The use(s) of the Lands permitted by this Agreement are the following:
Condition of Leased Premises Tenant hereby acknowledges that Xxxxxx has examined the leased premises prior to the signing of this Lease, or knowingly waived said examination. Tenant acknowledges that Tenant has not relied on any representations made by Landlord or Landlord’s agents regarding the condition of the leased premises and that Tenant takes premises in its AS-IS condition with no express or implied warranties or representations beyond those contained herein or required by applicable Georgia law. Xxxxxx agrees not to damage the premises through any act or omission, and to be responsible for any damages sustained through the acts or omissions of Tenant, Xxxxxx’s family or Xxxxxx’s invitees, licensees, and/or guests. If such damages are incurred, Tenant is required to pay for any resulting repairs at the same time and in addition to the next month’s rent payment, with consequences for non-payment identical to those for non- payment of rent described herein. At the expiration or termination of the Lease, Tenant shall return the leased premises in as good condition as when taken by Tenant at the commencement of the lease, with only normal wear-and-tear excepted. Modification Of This Lease Any modification of this lease shall not be binding upon Landlord unless in writing and signed by Landlord or Landlord’s authorized agent. No oral representation shall be effective to modify this Lease. If, as per the terms of this paragraph, any provision of this lease is newly added, modified, or stricken out, the remainder of this Lease shall remain in full force and effect.
POSSESSION OF THE PROPERTY The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on .
LIABILITY OF LANDLORD 29.1 It is expressly understood and agreed that the obligations of Landlord under this Lease shall be binding upon Landlord and its successors and assigns and any future owner of the Project only with respect to events occurring during its and their respective ownership of the Project. In addition, Tenant agrees to look solely to Landlord’s interest in the Project for recovery of any judgment against Landlord arising in connection with this Lease, it being agreed that neither Landlord nor any successor or assign of Landlord nor any future owner of the Project, nor any partner, shareholder, member, or officer of any of the foregoing shall ever be personally liable for any such judgment. The limitations of liability contained in this Section 29.1 shall inure to the benefit of Landlord’s and the Landlord Parties’ present and future partners, beneficiaries, officers, directors, trustees, shareholders, agents and employees, and their respective partners, heirs, successors and assigns. Under no circumstances shall any present or future partner of Landlord (if Landlord is a partnership), or trustee or beneficiary (if Landlord or any partner of Landlord is a trust), have any liability for the performance of Landlord’s obligations under this Lease. Notwithstanding any contrary provision herein, neither Landlord nor the Landlord Parties shall be liable under any circumstances for any indirect or consequential damages or any injury or damage to, or interference with, Tenant’s business, including but not limited to, loss of profits, loss of rents or other revenues, loss of business opportunity, loss of goodwill or loss of use, in each case, however occurring.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Modification of Land Act (2) For the purpose of this Agreement in respect of any land leased to the Company by the State the Land Act shall be deemed to be modified by —
Transfer of Land (a) The Developer may not transfer, assign or dispose of the whole or any part of its right, title or interest in the Land (present or future) or in the Development to another person (Transferee) unless before it sells, transfers or disposes of that right, title or interest:
