Possession Notice Sample Clauses

Possession Notice. Subject to the provision of Clause 9.6.1 above, on the Completion Date (which may include the Extended Period or the period required beyond the Extended Period due to Circumstances Of Force Majeure and other circumstances mentioned in Clause 9.5 above), the Developer shall serve a notice on the Buyer (Possession Notice) calling upon the Buyer to take exclusive physical possession. Within 15 (fifteen) days from the date of the Possession Notice (Date Of Possession Notice), the Buyer shall be bound to take over exclusive physical possession of the Said Flat, after fulfilling all obligations under this Agreement, including payment of all amounts due to the Developer, failing which it shall be deemed that the Buyer has taken possession on the 16th day of the Date Of Possession Notice (date of actual or deemed exclusive physical possession, Date Of Possession). From the Date Of Possession Notice, the Buyer shall become liable to pay all outgoings (such as Common Expenses/Maintenance Charges and Rates & Taxes), irrespective of whether the Buyer takes exclusive physical possession of the Said Flat And Appurtenances. In case the deeming provision comes into force, the Buyer confirms that the Buyer shall not claim to be in physical possession of the Said Flat And Appurtenances and the same shall be received by the Buyer only upon clearing all dues and performing all obligations.
Sample 1Sample 2Sample 3See All (17)
AutoNDA by SimpleDocs
Possession Notice. The Developer shall in writing (hereafter the "Notice") call upon the Purchaser to take possession of the Composite Unit within 21 (twenty-one) days of the date of the Notice.
Sample 1Sample 2Sample 3See All (8)
Possession Notice. The Vendor shall in writing call upon the Purchaser to take possession of the Composite Unit within 15 days of the date of dispatch of the Possession Notice.
Sample 1

Related to Possession Notice

  • Termination Notice If either Party, having become entitled to do so, decides to terminate this Agreement pursuant to the preceding Clause 8.2 (a) (i) or 8.2 (a) (ii), it shall issue Termination Notice setting out:

  • Termination Upon Notice Following thirty (30) days’ written notice, the State Entity may terminate the Contract in whole or in part without the payment of any penalty or incurring any further obligation to the Contractor. Following termination upon notice, the Contractor shall be entitled to compensation, upon submission of invoices and proper proof of claim, for goods and services provided under the Contract to the State Entity up to and including the date of termination.

  • Termination Notices If at any time prior to the expiration of the Property Approval Period, the Title Company receives a notice from Purchaser that Purchaser has exercised its termination right under Section 5.4, or if Purchaser does not timely deliver its Approval Notice under Section 5.4, the Title Company, within three (3) Business Days after the receipt of such notice or after the Contingency Date, as applicable, will deliver the Xxxxxxx Money Deposit to Purchaser without any notice to, or consent of, Seller being required. If at any time, except as provided in the preceding sentence, the Title Company receives a certificate of either Seller or of Purchaser (for purposes of this Section 4.6, the “Certifying Party”) stating that: (a) the Certifying Party is entitled to receive the Xxxxxxx Money Deposit pursuant to the terms of this Agreement, and (b) a copy of the certificate was delivered as provided herein to the other party (for purposes of this Section 4.6, the “Other Party”) prior to or contemporaneously with the giving of such certificate to the Title Company, then, the Title Company shall notify the Other Party in writing of the Title Company’s receipt of such certificate. Unless the Title Company has then previously received, or receives within three (3) Business Days after such written notification to the Other Party of the Title Company’s receipt of the Certifying Party’s certificate, contrary instructions from the Other Party, the Title Company, within one (1) Business Day after the expiration of the foregoing three (3) Business Day period, will deliver the Xxxxxxx Money Deposit to the Certifying Party, and thereupon the Title Company will be discharged and released from any and all liability hereunder. If the Title Company receives contrary instructions from the Other Party within three (3) Business Days following such written notification to the Other Party of the Title Company’s receipt of said certificate, the Title Company will not so deliver the Xxxxxxx Money Deposit, but will continue to hold the same pursuant hereto, subject to Section 4.7.

  • Notification of Delivery Destination Prior to final acceptance of contract requirements by STATE, PURCHASER shall notify STATE, in a form and manner prescribed by STATE, of the delivery destination of all timber purchased under this contract. STATE may hold PURCHASER's performance bond until satisfactory delivery destination information has been received. Notice of Transfer of State Timber. Prior to selling, trading, exchanging, or otherwise conveying unprocessed timber sold under this contract to any other person, PURCHASER must first obtain a certification of the person's eligibility to purchase unprocessed State timber, and their intent to comply with the terms and conditions contained in OAR 629-031-0005 through 629-031-0045. The certification shall be made in a form and manner prescribed by STATE, and shall be forwarded to STATE upon completion of the transaction. Obtaining the certification shall not relieve PURCHASER of the responsibility to provide STATE with an accounting of the delivery destination of that timber.

  • Notice of Displacement Where a notice of displacement or layoff actually results in a layoff, and prior to the layoff becoming effective, two (2) copies of such notice shall be sent to the Local designate.

  • Email Notice Any reference in this Agreement to “written notice” shall include notice by email, where there is reasonable certainty that such email notice originated either from a valid OANDA email address, or from the email address registered to your Account, as the case may be, and may be relied upon as valid and authentic written communication.

  • Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.

  • NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.

  • Termination on Notice The Province may terminate the Agreement at any time without liability, penalty, or costs upon giving at least 30 days’ Notice to the Recipient.

  • CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.

Time is Money Join Law Insider Premium to draft better contracts faster.