Performance upon Failure of Contractor Sample Clauses

Performance upon Failure of Contractor. Upon failure of the Contractor (including any of its subcontractors) to perform any of its obligations under this Agreement the County may, but shall not be obligated to perform or engage a third party to perform any of those obligations without prejudice to any other remedy or right it may have and the Contractor, immediately upon written demand, shall pay an amount equal to all costs and expenses incurred by the County in association therewith, plus interest on that amount from the date the cost or expense is incurred until it is paid at the rate of 1.5% per month (19.6% per annum). The County may, in its discretion, deduct any such amount, together with interest, from any payment then or thereafter due by the County to the Contractor, provided that such action shall not be deemed a waiver of any action that the County may pursue to collect any costs or expenses incurred herewith that exceed the amounts owed to the Contractor.
Sample 1Sample 2
AutoNDA by SimpleDocs
Performance upon Failure of Contractor. Upon failure of the Contractor (including any of its subcontractors) to perform any of its obligations under this Agreement the County may, but shall not be obligated to perform or engage a third party to perform any of those obligations without prejudice to any other remedy or right it may have and the Contractor, immediately upon written demand, shall pay an amount equal to all costs and expenses incurred by the County in association therewith, plus interest on that amount from the date the cost or expense is incurred until it is paid at the rate of 1.5% per month (19.6% per annum).
Sample 1
Performance upon Failure of Contractor. Upon failure of the Contractor (including any of its subcontractors) to perform any of its obligations under this Agreement the Community may, but shall not be obligated to perform or engage a third party to perform any of those obligations without prejudice to any other remedy or right it may have and the Contractor, immediately upon written demand, shall pay an amount equal to all costs and expenses incurred by the Community in association therewith, plus interest on that amount from the date the cost or expense is incurred until it is paid at the rate of 1.5% per month (19.6% per annum). The Community may, in its discretion, deduct any such amount, together with interest, from any payment then or thereafter due by the Community to the Contractor, provided that such action shall not be deemed a waiver of any action that the Community may pursue to collect any costs or expenses incurred herewith that exceed the amounts owed to the Contractor.
Sample 1

Related to Performance upon Failure of Contractor

  • Performance Delay Time is of the essence in the Vendor’s performance of this Agreement. If at any time it appears to Vendor that it may not meet any of the performance schedules or the scheduled completion date of the services to be performed for any reason, including labor disputes, Vendor shall immediately by verbal means (to be confirmed in writing) notify Customer of the reasons for and the estimated duration of such delay. If requested by Customer, Vendor shall make every effort to avoid or minimize the delay to the maximum extent possible including the expenditure of premium time. Any additional cost caused by these requirements of Customer shall be borne by Vendor, unless the delay in performance arises out of causes beyond the control and without the fault or negligence of Vendor or its subcontractors within the meaning of the Cancellation- Default clause herein. The foregoing requirements are in addition to any of Customer’s other rights and remedies as may be provided by law or this Agreement.

  • Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).

  • Performance Deficiency The Department or Customer may, in its sole discretion, notify the Contractor of the deficiency to be corrected, which correction must be made within a time-frame specified by the Department or Customer. The Contractor must provide the Department or Customer with a corrective action plan describing how the Contractor will address all issues of contract non-performance, unacceptable performance, and failure to meet the minimum performance levels, deliverable deficiencies, or contract non-compliance.

  • Failure of Conditions If the Conditions Precedent shall not have been satisfied or waived by February 27, 2015, either party may terminate this Lease and the Transfer Agreement by written notice of termination (the “Termination Notice”) delivered to the other party by February 27, 2015 (the “Failure of Conditions Termination Date”). Upon termination of this Lease under the terms of this Section 2, neither party hereto shall have any further claims or obligations under this Lease or the Transfer Agreement, except those obligations that expressly survive termination. Notwithstanding any provision of this Section 2.3 to the contrary, if the parties are unable to agree upon the initial Deferred Maintenance Items (as that term is defined in Section 9.2(c)(ii) below for the River Valley Facility to be included on Exhibit “E”, the sole remedy of the parties shall be to exclude the River Valley Facility from the Portfolio.

  • Excuse from Performance The Parties shall be excused from performing their respective obligations hereunder if they are prevented from so performing by reason of floods, earthquakes, other acts of nature, war, civil insurrection, riots, acts of any government (including judicial action), and other similar catastrophic events which are beyond the control of and not the fault of the Party claiming excuse from performance hereunder. Labor unrest, including but not limited to strike, work stoppage or slowdown, sick-out, picketing, or other concerted job action conducted by Contractor's employees or directed at Contractor is not an excuse from performance and Contractor shall be obligated to continue to provide service notwithstanding the occurrence of any or all of such events. The Party claiming excuse from performance shall, within two (2) Business Days after such Party has notice of such cause, give the other Party notice of the facts constituting such cause and asserting its claim to excuse under this Section. If either Party validly exercises its rights under this Section, the Parties hereby waive any claim against each other for any damages sustained thereby. The partial or complete interruption or discontinuance of Contractor's services caused by one or more of the events described in this Section shall not constitute a default by Contractor under this Agreement. Notwithstanding the foregoing, however, if Contractor is excused from performing its obligations hereunder for any of the causes listed in this Section for a period of thirty (30) calendar days or more, the SCWMA shall nevertheless have the right, in its sole discretion, to terminate this Agreement by giving ten (10) calendar days notice to Contractor unless Contractor has demonstrated, by the thirtieth (30th) calendar day, to the satisfaction of the SCWMA that the Contractor will resume services no later than the sixtieth (60th) day following the date service was interrupted or discontinued by Contractor.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Termination due to Event of Default (a) Termination due to Parties Event of Default

  • Performance by Contractor Where Pur- chaser’s employees, agents, contractors, Subcontractors, or their employees or agents perform Purchaser’s Opera- tions in connection with fire responsibilities, Purchaser’s obligations shall be the same as if performance was by Purchaser.

  • Breach of Grant Conditions 13.1 If the Recipient fails to comply with any of the conditions set out in this Grant Agreement, or if any of the events mentioned in Clause 13.2 occur, then the Commissioner may reduce, suspend, or withhold Grant payments, or require all or any part of the Grant to be repaid. The Recipient must repay any amount required to be repaid under this condition within 30 days of receiving the demand for repayment.

Time is Money Join Law Insider Premium to draft better contracts faster.