Performance as Directed Sample Clauses

Performance as Directed. At all times during the term hereof, including during the course of, and notwithstanding the existence of, any dispute, TSP shall perform as and if directed by the Joint Board in a diligent manner and without delay, shall abide by the Joint Board's decision or order, and shall comply with all applicable provisions of the Contract Documents. If a dispute arises regarding such performance or direction, the dispute shall be resolved in accordance with Section 19.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Performance as Directed. ‌ At all times during the term hereof, including during the course of, and notwithstanding the existence of, any Dispute, Design-Build Contractor shall perform as directed by IFA in a diligent manner and without delay, shall abide by IFA's decision or order, and shall comply with all applicable provisions of the PPA Documents. If a Dispute arises regarding such performance or direction, the Dispute shall be resolved in accordance with Section 19.
Sample 1Sample 2Sample 3
Performance as Directed. At all times during the term hereof, including during the course of and notwithstanding the existence of any Dispute, the DB Contractor shall perform in a diligent manner and without delay; shall abide by the District’s decision or order; and shall comply with all applicable provisions of the Contract.
Sample 1Sample 2Sample 3
Performance as Directed. At all times during the term of the Contract, including during the course of, and notwithstanding the existence of, any dispute, the Contractor shall perform as directed by the Authority, in a diligent manner and without delay, shall abide by the Authority’s decision, or order or formal Directive, and shall comply with all applicable provisions of the Contract Documents.
Sample 1
Performance as Directed. During the course of the Work and notwithstanding the existence of any Dispute, the Progressive Contractor shall perform as directed by the Department in a diligent manner and without delay, shall abide by the Department’s decision or order, and shall comply with all applicable provisions of the Contract Documents. If a Dispute arises regarding such performance or direction, the Dispute shall be resolved in accordance with Section 22 (Partnering & Disputes). If the Progressive Contractor receives direction from the Department in a form other than a Department-Directed Change and the Progressive Contractor believes that such direction constitutes a change to the Work, the Progressive Contractor shall request a Department- Directed Change confirming such direction.
Sample 1
Performance as Directed. Contractor shall, at all times, comply with all provisions of the Contract Documents. Contractor shall perform the Work diligently, without delay, and in compliance with VPRA’s decisions and orders, including during the course of a dispute between the Parties. The existence of a dispute between the Parties shall not be grounds for Contractor to stop Work on any aspect of the Project.
Sample 1
Performance as Directed. At all times during the term hereof, including during the course of, and notwithstanding the existence of, any dispute, Integrator shall perform as and if directed by TxDOT in a diligent manner and without delay, shall abide by TxDOT's decision or order, and shall comply with all applicable provisions of the Contract Documents. If a dispute arises regarding such performance or direction, the dispute shall be resolved in accordance with Section 19.
Sample 1
AutoNDA by SimpleDocs
Performance as Directed. At all times during the Term hereof, including during the course of, and notwithstanding the existence of, any dispute, Fabricator shall perform as directed by TxDOT in a diligent manner and without delay, shall abide by TxDOT's decision or order, and shall comply with all applicable provisions of the Contract Documents. If a dispute arises regarding such performance or direction, the dispute shall be resolved in accordance with Section 16. Section 3
Sample 1

Related to Performance as Directed

  • Performance Pay In accordance with Section 8 of the General Appropriations Act for Fiscal Year 2020-2021, contingent upon the availability of funds and at the Agency Head’s discretion, each agency is authorized to grant merit pay increases based on the employee’s exemplary performance, as evidenced by a performance evaluation conducted pursuant to Rule 60L-35, Florida Administrative Code.

  • PERFORMANCE PERIOD This Agreement shall be performed during the period which begins Oct 01 2020 and ends Sep 30 2022. All services under this Agreement must be rendered within this performance period, unless directly specified under a written change or extension provisioned under Article 14, which shall be fully executed by both parties to this Agreement.

  • Performance Measurement Satisfactory performance of this Contract will be measured by:

  • PERFORMANCE MEASUREMENTS Upon a particular Commission’s issuance of an Order pertaining to Performance Measurements in a proceeding expressly applicable to all CLECs generally, BellSouth shall implement in that state such Performance Measurements as of the date specified by the Commission. Performance Measurements that have been Ordered in a particular state can currently be accessed via the internet at xxxx://xxxx.xxxxxxxxx.xxx. The following Service Quality Measurements (SQM) plan as it presently exists and as it may be modified in the future, is being included as the performance measurements currently in place for the state of Tennessee. At such time that the TRA issues a subsequent Order pertaining to Performance Measurements, such Performance Measurements shall supersede the SQM contained in the Agreement. BellSouth Service Quality Measurement Plan‌ (SQM) Tennessee Performance Metrics Measurement Descriptions Version 2.00 Issue Date: July 1, 2003 Introduction

  • Performance Excused The Affected Party, to the extent rendered unable to perform its obligations or part thereof under this Agreement as a consequence of the Force Majeure Event shall be excused from performance of the obligations. Provided that, the excuse from performance shall be of no greater scope and of no longer duration than is reasonably warranted by the Force Majeure Event. Provided further, nothing contained herein shall absolve the Affected Party from any payment obligations accrued prior to the occurrence of the underlying Force Majeure Event.

  • Performance Monitoring A. Performance Monitoring of Subrecipient by County, State of California and/or HUD shall consist of requested and/or required written reporting, as well as onsite monitoring by County, State of California or HUD representatives.

  • Performance Management 17.1 The Contractor will appoint a suitable Account Manager to liaise with the Authority’s Strategic Contract Manager. Any/all changes to the terms and conditions of the Agreement will be agreed in writing between the Authority’s Strategic Contract Manager and the Contractor’s appointed representative.

  • Final Award Where the tribunal makes a final award against a party, the tribunal may award, separately or in combination, only:

  • Performance of Service 2.1 Appendix A (General Provisions), Articles 1 through 16, governs the performance of services under this contract. 2.2 Appendix B sets forth the liability and insurance provisions of this contract. 2.3 Appendix C sets forth the services to be performed by the contractor. ARTICLE 3.

  • Performance Bonus If Employee's employment is terminated by Employee with cause, or by Bank without cause, Employee shall be paid, in addition to the amounts payable under Sections 3.5 and 3.6 of the Agreement: (i) all non-forfeitable deferred compensation, if any; and (ii) unpaid performance bonus payments, if any, payable under Section 4.2 of the Agreement, which shall be declared earned and payable based upon performance up to, and shall be pro-rated as of, the date of termination. Employee shall not be entitled to such unpaid performance bonus payments if Employee's employment is terminated by Bank with cause, or by Employee without cause.

Time is Money Join Law Insider Premium to draft better contracts faster.