Owner’s Response Sample Clauses

The "Owner’s Response" clause defines the process and timeframe in which the owner must reply to requests, submissions, or notifications from the contractor or other parties involved in a project. Typically, this clause outlines specific deadlines for the owner to provide approvals, comments, or decisions, and may detail the consequences of delayed or absent responses, such as automatic approvals or extensions of time. Its core practical function is to ensure timely communication and decision-making, thereby preventing project delays and providing clarity on expectations for both parties.
Owner’s Response. The Owner will respond to the Time Extension Request by providing to the Contractor written notice of the number of days granted, if any, and giving its reason if this number differs from the number of days requested by the Contractor. 9.9.4.1 The Owner will not grant time extensions for delays that do not affect the Contract Completion Date. 9.9.4.2 The Owner will respond to each properly submitted Time Extension Request within fifteen (15) calendar days following receipt. If the Owner cannot reasonably make a determination about the Contractor’s entitlement to a time extension within that time, the Owner will notify the Contractor in writing. Unless otherwise agreed by the Contractor, the Owner has no more than fifteen (15) additional calendar days to prepare a final response. If the Owner fails to respond within forty-five (45) calendar days from the date the Time Extension Request is received, the Contractor is entitled to a time extension in the amount requested.
View SourceView Similar (124)
Owner’s Response. Owners shall, within thirty (30) Days after receipt of Contractor Response (the “Owners Response Period”): (i) notify Contractor as to whether it agrees or disagrees with such Contractor Response, and of Owners’ position regarding the effect of the Changes and the Change Order Request on the Target Price, Project Schedule, or other applicable provision of this Agreement and (ii) embody the agreed upon changes in the Work, the Target Price, or the Project Schedule in a document substantially in the form of Exhibit F-3 to be executed by the Parties (a “Change Order”). During the Owners Response Period, the Owners Representative and the Contractor’s Representative shall make themselves available and shall use reasonable efforts to meet or otherwise confer to discuss the Change Order Request, Contractor Response and the estimates therein contained, and to answer any questions or clarify any information provided with respect thereto. Owners or the Owners Representative may request the Contractor’s Representative to provide additional reasonable information or further information and data to the extent Contractor has failed to provide such information and data required to be provided or if there are errors, mistakes, or omissions in any information or data previously provided as part of the estimates contained in the Contractor Response. If Contractor fails to provide data or information required to be provided as part of the Contractor Response or fails to correct any errors or mistakes in such information or data, which prevents Owners from properly analyzing such data, or information, the Owners Response Period will be extended by that period of time commencing on the date Contractor receives notice of such failure, error, or mistake and ending on the date the correct data and information is received by Owners.
View Source
Owner’s Response. The Owner will respond to the Time Extension Request by providing to the CM-at-Risk written notice of the number of days granted, if any, and giving its reason if this number differs from the number of days requested by the CM-at-Risk. 9.9.4.1 The Owner will not grant time extensions for delays that do not affect the Contract Completion Date. 9.9.4.2 The Owner will respond to each properly submitted Time Extension Request within fifteen (15) calendar days following receipt. If the Owner cannot reasonably make a determination about the CM-at-Risk’s entitlement to a time extension within that time, the Owner will notify the CM-at-Risk in writing. Unless otherwise agreed by the CM-at- Risk, the Owner has no more than fifteen (15) additional calendar days to prepare a final response. If the Owner fails to respond within forty-five (45) calendar days from the date the Time Extension Request is received, the CM-at-Risk is entitled to a time extension in the amount requested.
View Source
Owner’s Response. Within ten days of receipt of the monthly pay application the Owner will: (1) Approve the pay application; or (2) Return the pay application to the Contractor with written reasons for refusing to approve payment.
View Source
Owner’s Response. Within fifteen (15) business days of its receipt of the Exercise Notice, Owner shall provide Host with a written estimate of the amounts comprising the Option Price.
View Source
Owner’s Response. If Offeree elects to purchase the Premises, then within five (5) business days after receipt of Offeree’s Election Notice, Owner shall return to Offeree and Escrow Holder as identified in the Purchase Agreement a signed counterpart of the Purchase Agreement with the Offer Terms incorporated therein. If the parties have not mutually executed and delivered the Purchase Agreement within thirty (30) days following Offeree’s Election Notice, or if Offeree does not elect to purchase the Premises, Owner may, at its election, and subject to the terms of this paragraph, during the twelve (12) month period following the date of the Offer Notice, enter into a letter of intent or purchase and sale agreement to sell and thereby Transfer the Premises described in the Offer Notice to any entity at such economic and non-economic terms as are acceptable to Owner and such third party purchaser without any Material Modification (as described in Section 1.2 below) to the Offer Terms. If Owner does not Transfer the Premises described in the Offer Notice within the above described twelve (12) month period (and subject to Section 1.2 below), then Owner shall submit to Offeree a new Offer Notice with respect to the Premises prior to selling the Premises upon terms and conditions set forth in the new Offer Notice. (i) Nothing herein shall prevent or restrict Offeree from making a subsequent offer for the Premises or from participating as a bidder in Owner’s marketing of the Premises. Owner shall use its reasonable efforts, without any liability for failure to do so, to furnish Offeree with the marketing information related to the Premises.
View Source

Related to Owner’s Response

  • Emergency Response Partners must develop, maintain, and carry out a response plan for public water system emergencies, including disease outbreaks, spills, operational failures, and water system contamination. Partners must notify DWS in a timely manner of emergencies that may affect drinking water supplies.

  • Incident Response Operator shall have a written incident response plan that reflects best practices and is consistent with industry standards and federal and state law for responding to a data breach, breach of security, privacy incident or unauthorized acquisition or use of any portion of Data, including PII, and agrees to provide LEA, upon request, an executive summary of the written incident response plan.

  • Agency Response a. OGS will consider all information relevant to the Formal Dispute, and may, in its discretion, suspend, modify, or cancel the disputed procurement/Contract action prior to issuance of a Formal Dispute decision. b. OGS reserves the right to require the filer to meet or participate in a conference call with OGS to discuss the Formal Dispute when, in its sole judgment, circumstances so warrant. c. OGS reserves the right to waive or extend the time requirements for decisions and final determinations on appeals herein prescribed when, in its sole judgment, circumstances so warrant. d. OGS reserves the right to consider or reject the merits of any Formal Dispute.

  • Timely and Sustained Response Interconnection Customer shall ensure that the Small Generating Facility’s real power response to sustained frequency deviations outside of the deadband setting is automatically provided and shall begin immediately after frequency deviates outside of the deadband, and to the extent the Small Generating Facility has operating capability in the direction needed to correct the frequency deviation. Interconnection Customer shall not block or otherwise inhibit the ability of the governor or equivalent controls to respond and shall ensure that the response is not inhibited, except under certain operational constraints including, but not limited to, ambient temperature limitations, physical energy limitations, outages of mechanical equipment, or regulatory requirements. The Small Generating Facility shall sustain the real power response at least until system frequency returns to a value within the deadband setting of the governor or equivalent controls. An Applicable Reliability Standard with equivalent or more stringent requirements shall supersede the above requirements.