Other claims not barred. In the absence of a change order, nothing in this paragraph 20 shall be deemed to restrict the CONTRACTOR'S right to pursue a claim under the Contract or for breach of contract.
Other claims not barred Sample Clauses
Related to Other claims not barred
Other Claims A claim for indemnification for any matter not involving a Third-Party Claim may be asserted by notice to the party from whom indemnification is sought and shall be paid promptly after such notice.
INDEMNITY FOR INFRINGEMENT CLAIMS EXCEPT TO THE EXTENT ARISING FROM MATERIALS PROVIDED TO CONTRACTOR BY UNIVERSITY, WHICH MATERIALS ARE UTILIZED BY CONTRACTOR IN THEIR UNALTERED FORM AND WITHOUT LIMITING THE GENERALITY OF THE INDEMNIFICATION CLAUSE REFERENCED IN THE HOLD HARMELSS SECTION BELOW, CONTRACTOR EXPRESSLY AGREES TO INDEMNIFY AND HOLD HARMLESS UNIVERSITY AND ITS DIRECTORS, OFFICERS, EMPLOYEES, AND AGENTS FROM AND AGAINST ANY AND ALL CLAIMS, SUITS, ACTIONS, LOSSES, LIABILITIES, COSTS, EXPENSES, AND DAMAGES ARISING OUT OF OR RELATED TO ANY CLAIMS THAT THE DELIVERABLES INFRINGE ANY PATENT, COPYRIGHT, TRADE SECRET, TRADEMARK, TRADE DRESS, MASK WORK, UTILITY DESIGN, OR OTHER PROPRIETARY RIGHT OF ANY THIRD PARTY. The indemnity under this Section will not apply to the extent such alleged or actual infringement arises as a result of (i) modifications of such work made by University which were not approved by Contractor, or (ii) Contractor’s compliance with any of University’s designs, specifications or instructions. In the event that a court of competent jurisdiction determines in a final, non-appealable order that the work is infringing in a manner for which Contractor is obligated to indemnify University pursuant to this Section, Contractor will, at its option, either (1) procure for University the right to continue using such infringing work; (2) replace the infringing work with a non-infringing item of like form, fit or function; or (3) modify the work so that it no longer infringes.
Indemnification/Hold Harmless The Exhibitor who signs this contract and each person associated therewith (i.e. employees, spouses, guests, survivors, heirs, executors and representatives) herein agrees to indemnify, defend, hold harmless, and to release and forever discharge from any and all known and unknown damages, injuries, death, loss, liabilities, claims, costs, penalties, demands, actions, causes of action, judgments, and liabilities of every kind and description (including court costs and attorney’s fees), occasioned by, resulting from, and/or related to conduct, actions, and/or omissions of anyone connected with this event, including: Xxxx Xxxx Xxxxxxxxxxx, Inc. d.b.a. Rod Shows, Fairplex, all other Exhibitors/Vendors at the event; and each of their respective owners, shareholders, officers, their directors, employees, agents, staff, volunteers, independent contractors, representatives and servants. Exhibitor covenants and agrees that in case Rod Shows shall be made party to any litigation commenced by or against exhibitor or relating to this agreement or to the booth space hereunder, then exhibitor shall and will pay all costs and expenses, including reasonable attorney fees and court costs, incurred by or imposed upon Rod Shows by virtue of any such litigation. SECURITY & PROPERTY DAMAGE Rod Shows will provide limited facility security and will exercise reasonable precaution for the protection of the exhibitors property. Rod Shows assumes no responsibility for loss or damage incurred during the rental period, or for any loss of items left onsite overnight. Neither Rod Shows or the vendor/exhibitor shall be responsible for any loss or damage to property of other party hereto including, but not limited to loss or damage occasioned by theft, fire, smoke, acts of God, public enemy, riot, civil commotion or other insurable hereto with respect to any loss or damage. It shall be the responsibility of Rod Shows and the Vendor/Exhibitor, respectively, to secure their own property insurance or otherwise protect themselves and their property against any such loss or damage. UNAVAILABILITY OF BOOTH SPACE
Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined).
Your Indemnity Obligations You hereby agree to indemnify, defend and hold Provider harmless from and against any and a l liability, losses, costs, and expenses (including attorneys’ fees) incurred by Provider, or any one of them, in connection with any claim, arising out of your use of the O ferings, Your Content, any violation of this XXXX, including any supplemental term, and/or your violation of the rights of any other party, including the Provider, or any one of them. Notwithstanding the foregoing, we may assume the defense and control of any indemnifiable claim, for which you agree to provide your cooperation and to assume the costs thereof.
Third Party Claims If any Indemnified Party receives notice of the assertion or commencement of any Action made or brought by any Person who is not a party to this Agreement or an Affiliate of a party to this Agreement or a Representative of the foregoing (a “Third-Party Claim”) against such Indemnified Party with respect to which the Indemnifying Party is obligated to provide indemnification under this Agreement, the Indemnified Party shall give the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than thirty (30) calendar days after receipt of such notice of such Third-Party Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Third-Party Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have the right to participate in, or by giving written notice to the Indemnified Party, to assume the defense of any Third-Party Claim at the Indemnifying Party’s expense and by the Indemnifying Party’s own counsel, and the Indemnified Party shall cooperate in good faith in such defense. In the event that the Indemnifying Party assumes the defense of any Third-Party Claim, subject to Section 8.03(b), it shall have the right to take such action as it deems necessary to avoid, dispute, defend, appeal or make counterclaims pertaining to any such Third-Party Claim in the name and on behalf of the Indemnified Party. The Indemnified Party shall have the right to participate in the defense of any Third-Party Claim with counsel selected by it subject to the Indemnifying Party’s right to control the defense thereof, provided that the fees and disbursements of such counsel shall be at the expense of the Indemnified Party.
WAIVER OF CLAIMS AND INDEMNITY AGREEMENT In consideration of the Releasees accepting my application for a Season Pass and permitting my use of the lifts, ski runs, trails, terrain parks, race courses, restaurants, day lodge, parking, access roads and other ski area facilities (hereinafter “the premises”), I hereby agree as follows:
Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
Defense of Third Party Claims Upon receipt by the Indemnifying Party of a notice from the Indemnified Party with respect to any claim of a third party against the Indemnified Party, for which the Indemnified Party seeks indemnification hereunder, the Indemnifying Party shall have the right to assume the defense of such claim, and the Indemnified Party shall cooperate to the extent reasonably requested by the Indemnifying Party in defense or prosecution thereof and shall furnish such records, information and testimony and attend all such conferences, discovery proceedings, hearings, trials and appeals as may be reasonably requested by the Indemnifying Party in connection therewith. If the Indemnifying Party shall elect to assume the defense of such claim, the Indemnified Party shall have the right to employ its own counsel in any such case, but the fees and expenses of such counsel shall be at the expense of the Indemnified Party. If the Indemnifying Party has assumed the defense of any claim against the Indemnified Party, the Indemnifying Party shall have the right to settle any claim for which indemnification has been sought and is available hereunder; provided that, to the extent that such settlement requires the Indemnified Party to take, or prohibits the Indemnified Party from taking, any action or purports to obligate the Indemnified Party, then the Indemnifying Party shall not settle such claim without the prior written consent of the Indemnified Party, such consent not to be unreasonably withheld, conditioned or delayed. If the Indemnifying Party does not assume the defense of a third party claim and disputes the Indemnified Party’s right to indemnification, the Indemnified Party shall have the right to assume control of the defense of such claim through counsel of its choice, the reasonable costs of which shall be at the Indemnifying Party’s expense in the event that the Indemnified Party’s right of indemnification is ultimately established through settlement, compromise or other legal proceeding. In no circumstance may the Indemnified Party compromise or settle a claim with a third party for which it seeks indemnification from the Indemnifying Party without first obtaining the prior written consent of the Indemnifying Party, such consent not to be unreasonably withheld, conditioned or delayed.
Workers’ Compensation and Employer’s Liability (i) Workers’ Compensation insurance indicating compliance with any applicable labor codes, acts, Laws or statutes, state or federal, where Seller performs Work.
